(65 ILCS 5/Art. 9 heading)
(65 ILCS 5/Art. 9 Div. 1 heading)
(65 ILCS 5/9-1-1) (from Ch. 24, par. 9-1-1)
Sec. 9-1-1.
The provisions of Sections 9-1-2 through 9-1-10 apply in all
municipalities unless otherwise provided in any of such sections.
The provisions of Sections 9-1-11 through 9-1-14 are alternative to and
not in exclusion of other methods of disposition of undistributed or
unclaimed money received from the making of any local improvement paid for
wholly or in part by special assessment or special taxation.
Any municipality in making local improvements may use either the
procedure set out in Division 2 of this Article or the procedure set out
in Division 3 of this Article subject to any restrictions appearing in
such divisions. Once a local improvement is begun under one of the
procedures it must be completed pursuant to the same procedure.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-1-2) (from Ch. 24, par. 9-1-2)
Sec. 9-1-2.
When the ordinance under which a local improvement is ordered
to be made provides that the improvement shall be made by general taxation,
the cost of the improvement shall be added to the annual appropriation
ordinance of the municipality ordering the improvement and shall be levied
and collected with and as a part of the general taxes of that municipality.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-1-3) (from Ch. 24, par. 9-1-3)
Sec. 9-1-3.
No ordinance ordering a local improvement shall be repealed
except on a written recommendation of the board of local improvements, or
committee on local improvements, as the case may be, stating the reasons
therefor. This section shall not apply to municipalities having a
population of less than 100,000.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-1-4) (from Ch. 24, par. 9-1-4)
Sec. 9-1-4.
The board of local improvements or committee on local
improvements, as the case may be, shall submit to the corporate
authorities, during the months of May and October of each year, for 3 years
following the completion of any public work, a written report of its
condition based upon a careful examination of the public work by the board
of local improvements, or by the committee on local improvements, as the
case may be, or by its representative, who shall be an experienced and
capable person of good
character. This section shall not apply to municipalities
having a population of less than 100,000.
(Source: P.A. 80-324.)
(65 ILCS 5/9-1-5) (from Ch. 24, par. 9-1-5)
Sec. 9-1-5.
Any municipality having any undistributed or unclaimed money
received from the making of any local improvement paid for wholly or in
part by special assessment or special taxation, and which money has
remained in the possession of the municipality for a period of 4 years or
more from the due date of the last installment undistributed or unclaimed
as a rebate or refund, after complying with all provisions for the
distribution of such rebates or refunds set out in Divisions 2 and 3 of
this Article, may set aside and transfer the money, so undistributed or
unclaimed, into a special fund to be known as the unclaimed rebate fund.
This fund may be used as provided in Sections 9-1-6 through 9-1-10.
(Source: Laws 1963, p. 2431.)
(65 ILCS 5/9-1-6) (from Ch. 24, par. 9-1-6)
Sec. 9-1-6.
Before the money so remaining undistributed or unclaimed
and in the possession of a municipality is set aside and transferred
into the unclaimed rebate fund, the board of local improvements, or the
committee on local improvements, as the case may be, of the municipality
shall have a notice published at least once a week for 8 successive
weeks in a newspaper published in the municipality, or, if no newspaper
is published therein, then in a newspaper with a general circulation
within the municipality. In municipalities with less than 500
population in which no newspaper is published, publication may be made
by posting a notice in 3 prominent places within the municipality.
The notice shall describe in a general manner the improvement in
which there is an undistributed or unclaimed rebate or refund, giving
the location of the improvement and the warrant number, and shall give
notice that the municipality, by ordinance after the expiration of 60
days from the date of the first publication of this notice, will set
aside and transfer all money which has remained for a period of 4 years,
or more, undistributed or unclaimed as a rebate or refund, into the
unclaimed rebate fund, and shall state that unless the money is claimed
by the person entitled thereto within the 60 day period, and the passage
of an ordinance by the municipality, all interest therein and all right
and title thereto shall be forfeited and barred.
A certificate of the publication of this notice, with a copy thereof,
accompanied by the affidavit of the publisher that the publication has
been made and setting forth the date of the first and last publication
thereof shall be filed in the office of the board of local improvements,
or the committee on local improvements, as the case may be. The board
or committee thereupon shall certify the fact of the publication to the
corporate authorities of the municipality and shall therewith recommend
the passage of an ordinance making transfer of the specified money into
the unclaimed rebate fund.
(Source: P.A. 80-179.)
(65 ILCS 5/9-1-7) (from Ch. 24, par. 9-1-7)
Sec. 9-1-7.
The corporate authorities, by ordinance, may create an
unclaimed rebate fund and may provide for its regulation and control, and
from time to time upon the recommendation specified in Section 9-1-6, may
direct that the undistributed and unclaimed money described in Section
9-1-5, be set aside and transferred to the unclaimed rebate fund.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-1-8) (from Ch. 24, par. 9-1-8)
Sec. 9-1-8.
Unless a claim is made by the person entitled thereto before
the passage of an ordinance by a municipality, as specified in Section
9-1-6, all interest therein and all right and title thereto of all
claimants shall be forfeited and barred. No action shall be begun or claim
made for any money undistributed or unclaimed as a rebate or refund,
received from the making of any local improvement, paid for wholly or in
part by special assessment or special taxation, after the money has
remained in the possession of a municipality undistributed or unclaimed as
a rebate or refund, for a period of 4 years or more from the due date of
the last installment, and where the money has been set aside and
transferred into the unclaimed rebate fund in the manner provided in
Sections 9-1-5 through 9-1-7.
(Source: Laws 1963, p. 2431.)
(65 ILCS 5/9-1-9) (from Ch. 24, par. 9-1-9)
Sec. 9-1-9.
Any municipality having an unclaimed rebate fund as provided in
Sections 9-1-5 through 9-1-7, by ordinance may at its option direct the use
of the money in that fund for any public purpose for which the
municipality is authorized by law to expend funds.
(Source: P.A. 84-581.)
(65 ILCS 5/9-1-10) (from Ch. 24, par. 9-1-10)
Sec. 9-1-10.
Whenever any municipality creates an unclaimed rebate fund and
by ordinance directs the use of the money in that fund for the purpose of
paying rebates or refunds due on any warrant for any special assessment or
special tax, the equivalent of any such money so used shall be returned to
the unclaimed rebate fund as soon as the warrants, which were deficient,
have been collected. Whenever any municipality directs the use of the money
in that fund for the purpose of paying unpaid special assessment vouchers
or special assessment bonds or special tax vouchers or interest or
deficiency in interest or public benefits in any warrant in which there is
a deficiency, the equivalent of any such money so used or any part thereof
shall be returned to the unclaimed rebate fund in the event there is
collected in the warrant any surplus in excess of the amount required to
pay the bonds and vouchers issued to anticipate such warrant. Whenever any
municipality directs the use of the money in the fund for the purpose of
purchasing any lot, block or tract or parcel of land, or any real estate at
any sale had to enforce the collection of special assessments or special
taxes, the proceeds of any redemption from such sale or from any sale of
the certificate or title acquired by such sale, to an amount equivalent to
any such money so used or any part thereof, shall be returned to the
unclaimed rebate fund.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-1-11) (from Ch. 24, par. 9-1-11)
Sec. 9-1-11.
Whenever the treasurer of any municipality has petitioned a
court of record for directions as to the distribution of undistributed or
unclaimed money received from the making of any local improvement paid for
wholly or in part by special assessment or special taxation, and, under
order of the court, public notice has been given of the amounts of rebates
payable and of the names of the persons entitled to them by publication one
time in a secular newspaper of general circulation in the county where the
municipality is located, and more than one year has elapsed since the
publication of the notice, the judge of the court of record may order the
money remaining unclaimed to be paid to the treasurer of the municipality
in trust. However, in all cases where all special assessment bonds in a
special assessment warrant have been paid and retired and where
reimbursements have been made, all moneys remaining in such warrants shall
be paid over and transferred to the general corporate fund of the
municipality.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-1-12) (from Ch. 24, par. 9-1-12)
Sec. 9-1-12.
If the corporate authorities have created an unclaimed rebate
fund, the treasurer shall transfer to the unclaimed rebate fund, in trust
any funds which the court of record may have ordered paid to such
treasurer. Subject to the provisions of Section 9-1-14, the funds may be
used as provided in Sections 9-1-9 and 9-1-10.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-1-13) (from Ch. 24, par. 9-1-13)
Sec. 9-1-13.
If the corporate authorities have not created an unclaimed
rebate fund, the treasurer shall transfer to the general fund of the
municipality, in trust, any funds which the court of record may order paid
to such treasurer. Subject to the provisions of Section 9-1-14, the funds
may be used as provided in Sections 9-1-9 and 9-1-10.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-1-14) (from Ch. 24, par. 9-1-14)
Sec. 9-1-14.
Any person entitled to any unclaimed sum of money paid into
the general fund of a municipality, in trust, under the provisions of
Sections 9-1-12 or 9-1-13 must apply or make claim, or commence action for
the repayment thereof in the manner and within the time set forth in
Sections 9-1-5 through 9-1-10.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/Art. 9 Div. 2 heading)
(65 ILCS 5/9-2-1) (from Ch. 24, par. 9-2-1)
Sec. 9-2-1.
This Division 2 applies to all cities and villages incorporated
under this Code and to any city, village or incorporated town organized
under a special charter if such city, village or incorporated town has,
prior to, on or after the effective date of this Code, adopted the
provisions of this Division 2 as provided herein.
The corporate authorities of the specified municipalities have the power
to make such local improvements as are authorized by law, by special
assessment or special taxation of contiguous property, or by general
taxation, or otherwise, as such corporate authorities prescribe by
ordinance.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-2) (from Ch. 24, par. 9-2-2)
Sec. 9-2-2.
In this Division 2, the following terms have the meaning
ascribed to them unless the context indicates otherwise:
"Municipality" means any city, village or incorporated town which comes
within the scope of this Division 2 as determined by the provisions of
Section 9-2-1.
"Work" means labor performed or material used, or both, as the corporate
authorities may determine.
"Subways" means all tunnels, entrances, exits, passageways, connections,
approaches, inclines, elevators, stations and other structures, equipment,
appliances or appurtenant property appropriate to a system of subways.
"Pedestrian Mall" means one or more streets, or portions thereof, on
which vehicular traffic is or is to be restricted in whole or in part and
which is or is to be used exclusively or primarily for pedestrian travel.
"Prime Commercial Rate" means such prime rate as from time to time is
publicly announced by the largest commercial banking institution located
in this State, measured in terms of total assets.
(Source: P.A. 82-642.)
(65 ILCS 5/9-2-3) (from Ch. 24, par. 9-2-3)
Sec. 9-2-3.
Any municipality which after July 6, 1937, enters into an
agreement with the Federal Government or any agency thereof or other
governmental agency for the construction, extension, improvement or repair
of any local improvements with the aid of a Federal grant of money, or any
other governmental grant of money, services, or materials may, for the
purpose of raising its portion of the funds necessary for such
construction, extension, improvement, or repair, provide a special tax or
special assessment of the property benefited, to pay for the share of that
improvement to be met by the municipality. This special tax or special
assessment shall be levied and collected, and the proceedings incident
thereto shall be carried on, in conformance with the provisions of this
Division 2, in so far as those provisions are applicable.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-4) (from Ch. 24, par. 9-2-4)
Sec. 9-2-4.
Any municipality in or adjacent to which any Federal
defense project is in progress or is about to be in progress, may, if
the Defense Department of the United States, or any officer thereof
designated by the Secretary of Defense for such purpose, certifies that
the water supply, sewage system or highway system of such municipality
is inadequate to provide sufficient facilities due to the increase or
anticipated increase in the population of such municipality on account
of such project, provide a special tax or special assessment of the
property benefited, (or in case the Federal Government or any agency
thereof grants moneys, services or materials, for raising its portion of
the funds necessary), for such construction, extension, improvement or
repair. Such special tax or special assessment shall be levied and
collected and the proceedings incident thereto shall be carried on, in
conformance with the provisions of this Division 2, in so far as such
provisions are applicable, with the following exceptions: (1) no public
hearing, as provided in Section 9-2-10, shall be necessary; (2) if the
improvement is accomplished through Federal aid which takes the form of
the supplying of labor and materials rather than funds, no public
letting of contract shall be required; (3) to meet such emergency, the
municipality may secure temporary financing therefor and levy such
special tax or assessment during construction of the improvement or at
any time within one year thereafter and utilize the proceeds of such
levy or assessment (or bonds issued in anticipation thereof) to retire
such temporary financing when and if such tax or assessment shall be
confirmed by the Circuit Court wherein such municipality shall be
situated.
(Source: P.A. 80-1495.)
(65 ILCS 5/9-2-4.5)
Sec. 9-2-4.5. Special assessment for payment of costs associated with certain ordinance violations.
(a) For purposes of this Section, "Code" means any municipal ordinance that requires, after notice, the cutting of grass and weeds, the removal of garbage and debris, the removal of inoperable motor vehicles, and rodent and vermin abatement.
(b) In addition to any other method authorized by law, if (i) a property owner is cited with a Code violation, (ii) non-compliance is found upon reinspection of the property after the due date for compliance with an order to correct the Code violation or with an order for abatement, (iii) costs for services rendered by the municipality to correct the Code violation remain unpaid at the point in time that they would become a debt due and owing the municipality, as provided in Division 31.1 of Article 11 of the Illinois Municipal Code, and (iv) a lien has been filed of record by the municipality in the office of the recorder in the county in which the property is located, then those costs may be collected as a special assessment on the property under this Division. Upon payment of the costs by the owner of record or persons interested in the property, the lien shall be released by the municipality and the release shall be filed of record in the same manner as the filing of notice of the lien.
(Source: P.A. 93-993, eff. 1-1-05.)
(65 ILCS 5/9-2-5) (from Ch. 24, par. 9-2-5)
Sec. 9-2-5.
When any municipality provides by ordinance for the making of
any local improvement, it shall prescribe by the same ordinance whether the
improvement shall be made by special assessment or special taxation of
contiguous property, or by general taxation, or by special assessment of
contiguous property and by general taxation, or by special taxation of
contiguous property and by general taxation.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-6) (from Ch. 24, par. 9-2-6)
Sec. 9-2-6.
No ordinance for any local improvement, to be paid wholly or in
part by special assessment or special taxation, shall be considered or
passed by the corporate authorities of any such municipality unless the
ordinance is first recommended by the board of local improvements;
provided, however, that after the ordinance for any local improvement has
been adopted by the corporate authorities and before the same is confirmed
in court, the corporate authorities, upon recommendation of the board of
local improvements, may by ordinance abandon any portion of the proposed
improvement without further action by or hearing before the board.
(Source: Laws 1963, p. 2424.)
(65 ILCS 5/9-2-7) (from Ch. 24, par. 9-2-7)
Sec. 9-2-7.
In cities having a population of 500,000 or more, there is
created a board of local improvements consisting of the superintendent of
special assessments and 5 other members. These 5 other members shall be
nominated by the mayor and shall be confirmed by the city council. None of
the members of the board, except the superintendent of special assessments,
shall hold any other office or position in any government department of the
city. The Board shall elect from its members a president, a vice president,
and an assistant secretary. The superintendent of special assessments shall
be ex-officio secretary of the board. In the absence or the inability of
the president or secretary to act, the vice president for the president and
the assistant secretary for the secretary have full power to sign and
execute contracts, vouchers, bonds, payrolls, and all other papers,
documents, and instruments necessary. The board shall hold regular and
special sessions, as it may determine, for the transaction of all business
in rooms accessible to the public, to be provided by the city council. The
city council of the city shall provide for salaries for the board of local
improvements.
In cities having a population of 50,000 or more and less than 500,000,
there is created a board of local improvements consisting of 6 members, of
which board the commissioner of public works shall be the president. The
other members of this board shall be the superintendent of streets, the
superintendent of sewers, the superintendent of special assessments, the
city engineer and the city clerk, or if there is no office of City Clerk,
the City Comptroller.
In cities having a population of less than 50,000, and in villages and
incorporated towns, the board of local improvements shall consist of the
mayor of the city, or the president of the village or incorporated town,
and the public engineer and the superintendent of streets of the
municipality, where such officers are provided for by ordinance. But if at
any time such officers are not so provided for, the corporate authorities,
by ordinance, shall designate 2 or more members of their body who, with the
mayor or president of the village or incorporated town shall constitute the
members of the board, until otherwise provided by ordinance. The mayor or
president, as the case may be, shall be president of the board.
The corporate authorities of any municipality having a population of
more than 18,000 and less than 100,000, may provide by ordinance for the
payment of salaries to the members of the board of local improvements, but
if any member of such a board holds any other office in the government of
that municipality, his salary as member of the board shall not exceed the
sum of $100 per month.
However, in cities, having a population of less than 100,000, and in
villages, where such cities and villages prior to or after the effective
date of this Code adopt the commission form of municipal government,
corporate authorities of such cities and villages may provide by ordinance
that the board of local improvements shall consist of the mayor and any 2
or more of the commissioners, regardless of whether or not the offices of
public engineer and superintendent of streets are provided for by
ordinance.
(Source: P.A. 82-432.)
(65 ILCS 5/9-2-8) (from Ch. 24, par. 9-2-8)
Sec. 9-2-8.
In cities having a population of 500,000 or more, and having a
chief clerk of special assessments, that chief clerk of special
assessments, in the event of the absence or inability to act of the
superintendent of special assessments, may, with full effect, perform all
acts and duties provided for in this Division 2 to be performed by the
superintendent of special assessments.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-9) (from Ch. 24, par. 9-2-9)
Sec. 9-2-9.
Preliminary procedure for local improvements by special
assessment. All ordinances for local improvements to be paid for wholly or
in part by special assessment or special taxation shall originate with the
board of local improvements. Petitions for any local improvement shall be
addressed to that board. The board may originate a scheme for any local
improvement to be paid for by special assessment or special tax, either
with or without a petition, and in either case shall adopt a resolution
describing the proposed improvement. This resolution may provide that
specifications for the proposed improvement be made part of the resolution
by reference to specifications previously adopted by resolution by the
municipality, or to specifications adopted or published by the State of
Illinois or a political subdivision thereof, provided that a copy of the
specifications so adopted by reference is on file in the office of the
clerk of the municipality. This resolution shall be at once transcribed
into the records of the board.
The proposed local improvement may consist of the acquisition of the
necessary interests in real property and the construction of
any public improvement or any combination of public improvements, including,
but not limited to, streets,
storm drain sewers, water mains, sanitary
sewer improvements, sidewalks, walkways, bicycle paths, landscaping, lighting
improvements, signage improvements, vehicular parking improvements, any
additional improvements necessary to provide access to the public improvements,
and all necessary
appurtenances in
a local contiguous area pursuant to a single special assessment project,
provided that in
assessing each lot, block, tract, and parcel of property, the commissioner so
assessing shall take into consideration whether each lot, block, tract, or
parcel is benefited by all or only some of the improvements combined into the
single special assessment project.
For purposes hereof, a local contiguous area shall be defined as an area
in which all of the lots, blocks, tracts, or parcels located within the
boundaries thereof will be benefited by one or more of the proposed
improvements.
The fact that more than one improvement is
being constructed as part of a single special assessment project shall not be
grounds
for an objection by an assessee to the special assessment proceeding in
court.
Whenever the proposed improvement requires that private or public
property be taken or damaged, the resolution shall describe the property
proposed to be taken or damaged for that purpose. The board, by the same
resolution, shall fix a day and hour for a public hearing thereon. The
hearing shall not be less than 10 days after the adoption of the
resolution. The board shall also have an estimate of the cost of the
improvement (omitting land to be acquired) made in writing by the engineer
of the board, (if there is an engineer, if not, then by the president) over
his signature. This estimate shall be itemized to the satisfaction of the
board and shall be made a part of the record of the resolution. However,
such an estimate is not required in municipalities having a population of
100,000 or more when the proposed improvement consists only of taking or
damaging private or public property. And in cities and villages which have
adopted prior to the effective date of this Code or which after the
effective date of this Code adopt the commission form of municipal
government, the estimate of the cost of the improvement, (omitting land to
be acquired), shall be made in writing by the public engineer if there is
one, of the city or village, if not, then by the mayor or president of the
city or village.
Notice of the time and place of the public hearing shall be sent by mail
directed to the person who paid the general taxes for the last preceding
year on each lot, block, tract, or parcel of land fronting on the proposed
improvement not less than 5 days prior to the time set for the public
hearing. These notices shall contain (1) the substance of the resolution
adopted by the board, (2) when an estimate is required by this Division 2
the estimate of the cost of the proposed improvement, and (3) a
notification that the extent, nature, kind, character, and (when an
estimate is required by this article) the estimated cost of the proposed
improvement may be changed by the board at the public hearing thereon. If
upon the hearing the board deems the proposed improvement desirable, it
shall adopt a resolution and prepare and submit an ordinance therefor. But
in proceedings only for the laying, building, constructing, or renewing of
any sidewalk, water service pipe, or house drain, no resolution, public
hearing, or preliminary proceedings leading up to the same are necessary.
In such proceedings the board may submit to the corporate authorities an
ordinance, together with its recommendation and (when an estimate is
required) the estimated cost of the improvement, as made by the engineer.
Such proceedings shall have the same effect as though a public hearing had
been held thereon.
In the event that a local improvement is to be constructed with the
assistance of any agency of the Federal government, or other governmental
agency, the resolution of the board of local improvements shall set forth
that fact and the estimate of cost shall set forth and indicate, in dollars
and cents, the estimated amount of assistance to be so provided.
(Source: P.A. 93-196, eff. 1-1-04.)
(65 ILCS 5/9-2-10) (from Ch. 24, par. 9-2-10)
Sec. 9-2-10.
At the time and place fixed in the specified notice for the
public hearing, the board of local improvements shall meet and hear the
representations of any person desiring to be heard on the subject of the
necessity for the proposed improvement, the nature thereof, or the cost as
estimated. In case any person appears to object to the proposed improvement
or any of the elements thereof, the board shall adopt a new resolution
abandoning the proposed scheme or adhering thereto, or changing, altering,
or modifying the extent, nature, kind, character, and estimated cost,
provided the change does not increase the estimated cost of the improvement
to exceed 20% of the same, without a further public hearing thereon, as it
considers most desirable. Thereupon, if the proposed improvement is not
abandoned, the board shall have an ordinance prepared therefor, to be
submitted to the corporate authorities. This ordinance shall prescribe the
nature, character, locality, and description of the improvement and shall
provide whether the improvement shall be made wholly or in part by special
assessment or special taxation of contiguous property. This ordinance may
provide that specifications for the proposed improvement be made part of
the ordinance by reference to specifications previously adopted by
ordinance by the municipality, or to specifications adopted or published by
the State of Illinois or a political subdivision thereof, provided that a
copy of the specifications so adopted by reference is on file in the office
of the clerk of the municipality. If the improvement is to be paid in part
only by special assessment or special taxation, the ordinance shall so
state.
If property is to be taken or damaged for the improvement, the ordinance
shall describe the property with reasonable certainty.
In cities having a population of 500,000 or over when a remonstrance
petition is filed by the owners of a majority of the frontage on the line
of the proposed improvement with the board of local improvements within 30
days after the public hearing thereon, the board shall thereupon stay all
proceedings therein for one year from that date. This remonstrance petition
shall contain the signatures of the owners or legal representatives, the
description of the property owned or represented, and the number of feet so
owned or represented and shall be verified by affidavit of one or more
property owners fronting on the line of the proposed improvement, setting
forth that the party making the affidavit is a property owner, fronting on
the proposed improvement and that the parties who signed the petition are
the owners or legal representatives of the property described therein.
(Source: Laws 1963, p. 2425.)
(65 ILCS 5/9-2-11) (from Ch. 24, par. 9-2-11)
Sec. 9-2-11.
Accompanying any ordinance for a local improvement presented
by the board of local improvements to the corporate authorities shall be a
recommendation of such improvement by the board, signed by at least a
majority of the members thereof. The recommendation by the board shall be
prima facie evidence that all the preliminary requirements of the law have
been complied with. If a variance is shown on the proceedings in the court,
it shall not affect the validity of the proceeding, unless the court deems
the variance willful or substantial.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-12) (from Ch. 24, par. 9-2-12)
Sec. 9-2-12.
An estimate of the cost of the improvement, including the cost
of engineering services, as originally contemplated, or as changed,
altered, or modified at the public hearing, itemized so far as the board of
local improvements thinks necessary, shall be presented to the corporate
authorities, except when rendered unnecessary by Section 9-2-9, together
with the specified ordinance and recommendation. This estimate of cost
shall be presented over the signature of the engineer of the board, if
there is one, if not, then of the signature of the president of the board,
who shall certify that in his opinion the estimate does not exceed the
probable cost of the improvement proposed and the lawful expenses attending
the improvement.
However, in a city or village which has adopted or which hereafter
adopts the commission form of municipal government, this estimate of cost
shall be over the signature of the public engineer, if there is one, and if
there is no such public engineer, then over the signature of the mayor or
president of that city or village, who shall certify that in his opinion
the estimate does not exceed the probable cost of the improvement proposed
and the lawful expenses attending the improvement.
The recommendation by the board shall be prima facie evidence that it is
based upon a full compliance with the requirements of this Division 2.
In the event the improvement is to be constructed with assistance from
any agency of the Federal Government, or other governmental agency, the
estimate of cost shall state this fact and shall set forth the estimated
amount in dollars and cents that is to be provided by the agency of the
Federal Government or other governmental agency.
The commissioners, superintendent of special assessments, or other
person appointed to make the assessments as provided hereinafter, shall
make a true and impartial assessment upon the petitioning municipality and
the property benefited by such improvement, of that portion of the
estimated cost that is within the benefits exclusive of the amount to be
provided by the agency of the Federal Government or other governmental
agency.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-13) (from Ch. 24, par. 9-2-13)
Sec. 9-2-13. Publication and posting of ordinances. Upon the presentation to the corporate authorities of the
proposed ordinance, together with the required recommendation and estimate,
if the estimate of cost exceeds the sum of $1,000,000, exclusive of the
amount to be paid for land to be taken or damaged, the ordinance shall be
referred to the proper committee and published in the usual way or posted on the municipality's Internet website, in full,
with the recommendation and estimate, at least 10 days before any action is
taken thereon by the corporate authorities. Whenever any plat, plan,
profile, or drawing is a part of the ordinance, or is attached thereto as a
part thereof, or is referred to by the ordinance, it is not necessary to
publish or post that plat, plan, profile, or drawing in connection with the
publication or posting of the ordinance.
(Source: P.A. 96-1075, eff. 7-16-10.)
(65 ILCS 5/9-2-14) (from Ch. 24, par. 9-2-14)
Sec. 9-2-14.
If the ordinance provides for improvements which require the
taking or damaging of property, the proceeding for making just compensation
therefor shall be as described in Sections 9-2-15 through 9-2-37. Such a
proceeding also shall be governed by the remaining sections of this
Division 2, so far as not in conflict with Sections 9-2-15 through 9-2-37.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-15) (from Ch. 24, par. 9-2-15)
Sec. 9-2-15.
Whenever any local improvement ordinance is passed by the
corporate authorities of any municipality, to be paid for wholly or in part
by special assessment, or by special taxation, the making of which will
require that private or public property be taken or damaged for public use,
the municipality, either in that ordinance or by subsequent order, shall
designate some officer to file a petition in the circuit court of the
county in which the municipality is situated, or if the municipality is
situated in more than one county and the proposed improvement or the
property to be taken or damaged, or both, lies in more than one county,
then in the circuit court in the county in which the major part of the
territory to be affected thereby is situated. Such petition shall be filed
in the name of the municipality, praying that steps may be taken to
ascertain the just compensation to be made for private or public property
to be taken or damaged for the improvement or purpose specified in the
ordinance, and to ascertain what property will be benefited by the
improvement, and the amount of those benefits.
(Source: Laws 1967, p. 3762.)
(65 ILCS 5/9-2-16) (from Ch. 24, par. 9-2-16)
Sec. 9-2-16.
The petition required in Section 9-2-15 shall contain a
reasonably accurate description of lots, blocks, tracts, and parcels of land
which are to be taken or damaged; provided that in counties in which a property
index number system has been established in accordance with Section 9-45 of the
Property Tax Code, the index number shall be given in addition to the
legal description. There shall be filed with or attached to the petition a copy
of the specified condemnation ordinance, certified by the clerk, under the
corporate seal. Failure to file such a copy shall not affect the jurisdiction
of the court to proceed in that cause and to act upon the petition, but if it
appears in the cause that a copy of the ordinance has not been attached to or
filed with the petition before the report of the commissioners is filed, as
provided in Section 9-2-18, then, upon motion of any person whose real estate
is to be taken, or to be assessed, the entire petition and proceedings shall be
dismissed.
Upon the filing of the petition, the court shall enter an order
designating 2 competent persons as commissioners, to act with the
superintendent of special assessments where that officer is provided for by
this Code, and in other cases to act with the president of the board of
local improvements. These 3 commissioners shall investigate and report to
the court the just compensation to be made to the respective owners of
private or public property which is to be taken or damaged for the
specified improvement, and also what real estate will be benefited by that
improvement, and the amount of those benefits to each parcel. Neither of
the persons designated by the court shall be an employee of the petitioning
municipality and both shall be disinterested persons. They shall be allowed
a fee for their services which shall be fixed by the court in advance. The
amounts so allowed may be reviewed by the court upon motion, and may be
taxed as costs and included in the amount to be assessed, except that in
cities having a population of 500,000 or more, the commissioners' fees
shall be either paid by the city out of its general fund or included among
the expenses to be defrayed out of the sum not to exceed 5% of the amount
of the assessment, for which provision is made in Section 9-2-139. These 3
commissioners shall be duly sworn to make a true and just assessment of the
cost of the improvement according to law. The concurrence of any 2 in a
report shall be sufficient.
(Source: P.A. 88-670, eff. 12-2-94.)
(65 ILCS 5/9-2-17) (from Ch. 24, par. 9-2-17)
Sec. 9-2-17.
When a petition is filed, a certified copy of
the petition and the assessment
roll of the
municipality, hereinafter required in Section 9-2-18, shall be
immediately delivered by the clerk of the court to the petitioner, who shall
record the certified copy with the recorder of deeds of that
county, to be kept as part of
the permanent records of the office of the
recorder.
A certified copy of any order or judgment to divide,
modify, alter, change, reduce, increase, annul, confirm, or deny anything
contained within the assessment roll
shall be immediately delivered by the clerk of the court to the
petitioner, who shall record the certified copy with the recorder of
that county, to be kept as part of the
permanent records of the office of the recorder.
(Source: P.A. 85-1252.)
(65 ILCS 5/9-2-18) (from Ch. 24, par. 9-2-18)
Sec. 9-2-18.
The commissioners shall make an investigation as required and
prepare and file in court their report accordingly. In this report the
commissioners shall in one column describe the respective parcels of property
to be taken or damaged for the specified improvement and, in counties in which
a property index number system has been established in accordance with Section
9-45 of the Property Tax Code, shall give the index number in
addition to the legal description; in another column the respective owners of
record of those parcels of land, the name and residence of each such owner
being set opposite his own property; in another column the name and residence
of the occupant, where the property is occupied, so far as known to the
commissioners or can be found upon diligent inquiry; in another column the
amount of the value of each parcel to be taken for the improvement, setting the
amount opposite the property to which it relates; and in another column the
amount of damages, if any, which in the opinion of the commissioners, will
result to any parcel of land not taken, by reason of the improvement,
describing each parcel so damaged by a reasonably accurate description.
The commissioners shall further estimate and report what proportion of
the total cost of the improvement (including therein their estimate of
value and damages, and, when an estimate is required by this Article, the
estimate of the cost of such proceeding) will be of benefit to the public,
and what proportion thereof will be of benefit to the property. The
commissioners shall apportion the total cost of the improvement between the
municipality and the property so that each will bear its relative equitable
proportion. Having found these amounts, the commissioners shall further
report what lots, blocks, tracts, and parcels of land will be specially
benefited by the improvement, shall describe them by a reasonably accurate
description, and shall apportion and assess the amount so found to be of
benefit to the property upon the several lots, blocks, tracts, and parcels
of land in the proportion in which they will be severally benefited by the
improvement. But no lot, block, tract, or parcel of land shall be assessed
a greater amount than it will be actually benefited, except that the
apportionment and assessment shall include the anticipated fees for the
recording of documents as provided in this Article.
(Source: P.A. 88-670, eff. 12-2-94.)
(65 ILCS 5/9-2-19) (from Ch. 24, par. 9-2-19)
Sec. 9-2-19.
Whenever any local improvement provided in any ordinance
passed by virtue of this Division 2 consists of a system of waterworks or a
bridge or viaduct, or extension of water mains which are a part of any
municipal waterworks system, any portion of the cost of which is to be
defrayed by special assessment, it may be provided by the ordinance for the
improvement or by ordinance passed at any time before the confirmation of
the assessment roll, that the aggregate amount assessed and each individual
assessment, and also the assessment against the municipality for public
benefits and on account of property owned by it, may be divided into not
exceeding 30 installments in the manner provided in Section 9-2-48. The
provisions of this Section 9-2-19 shall not apply to any city having a
population of 500,000 or more.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-20) (from Ch. 24, par. 9-2-20)
Sec. 9-2-20.
If the amount awarded to any person for property taken or
damaged for an improvement under this Division 2 is greater than the amount
assessed against the property for that improvement, or if the benefit is
greater than the damage, in either case the difference only shall be collectible
of the owner or be paid to him.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-21) (from Ch. 24, par. 9-2-21)
Sec. 9-2-21.
In the assessment of damages and benefits for the opening of
any street or alley, the commissioners, where part of the land to be laid
out into that street or alley has been theretofore donated by any person
for that street or alley, may appraise the value of the land so donated. Or
in cases where such a donation is made after the filing of any petition in
the circuit court praying that steps be taken to levy a
special assessment for the opening of any street or alley, and after the
making of the assessment roll as provided in this Division 2, the court may
appraise, or may have a jury appraise, the value of the land so donated.
The commissioners or the court, as the case may be, shall apply the value
thereof, so far as the amount so appraised shall go, as an offset to the
benefits assessed against the person making such a donation, or parties
claiming under such person. Nothing contained in this section authorizes
any person by whom such a donation is made to claim from the municipality
the amount of that appraisement, except as an offset, as provided in this
section. Where the assessment is only for the widening of any street which
may have been theretofore donated either in whole or in part, to the public
by the proprietors of the adjoining land, the commissioners, in their
discretion, may make such allowance therefor in their assessment of
benefits as seems to them equitable and just. But in either such case the
commissioners shall state in their report the amount of that allowance, and
the allowance shall be subject to review, as the court shall direct.
(Source: P.A. 79-1361.)
(65 ILCS 5/9-2-22) (from Ch. 24, par. 9-2-22)
Sec. 9-2-22.
The commissioners shall return their report to the court in
which the specified petition was filed, and file the report with the clerk
thereof, with their certificate, duly verified, stating in substance that
they have carefully examined the questions referred to in their report, and
that in their opinion the amounts awarded for damages and value therein,
and the respective amounts assessed against the property specially
benefited, and also the apportionment of the cost of the improvement
between the public and the property assessed, and the allowance for
property theretofore dedicated, if any, are correct, equitable, and just.
The return and filing of this report shall be deemed an application by the
petitioner for judgment of condemnation of the property so to be taken or
damaged, and for a confirmation of the assessment of benefit.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-23) (from Ch. 24, par. 9-2-23)
Sec. 9-2-23.
The superintendent of special assessments, or president of the
board of local improvements, as the case may be, shall file with the
commissioners' report an affidavit made by himself or by some employee of
his office, that (1) the affiant has carefully examined the records in the
recorder's office of the specified county or counties for the names of the
owners of record of the several lots, blocks, tracts, and parcels of land
to be taken or damaged for the improvement, (2) that the affiant made a
careful examination of the collector's books showing the payments of
general taxes during the last preceding year in which taxes were paid on
the respective lots, blocks, tracts, and parcels of land against which
benefits are assessed in the commissioners' report, to ascertain the person
or persons who last paid the taxes on those respective lots, blocks,
tracts, and parcels of land, (3) that the names of those owners of record
and persons who paid those taxes are correctly shown in the columns or
schedules of ownership and of persons who paid those taxes in the
commissioners' report, (4) that he has diligently inquired as to the
residence of the respective owners of property to be taken or damaged for
the improvement and of the persons who paid the general taxes during the
last preceding calendar year in which general taxes were paid on all the
respective lots, blocks, tracts, and parcels of land against which benefits
have been assessed in the commissioners' report (specifying the nature of
the inquiry and examination he has made for that purpose), (5) that the
residences of the owners and parties paying those general taxes are
correctly stated, according to the result of his examination, in the column
or schedule of residences in the commissioners' report, and (6) that in all
cases where he has been unable to find the residence of the owner of the
record title, he has examined the return of the collector's warrant for
taxes on real estate for the last preceding year, in which the taxes were
paid, and has set opposite each such parcel whose owner has not been found,
the name of the person who last paid the tax on that parcel, together with
his place of residence, wherever, on diligent inquiry, he was able to find
the same. This affidavit, or an affidavit filed therewith, shall further
state that the affiant has visited each of the parcels of land to be taken
or damaged for the improvement described in the commissioners' report, for
the purpose of ascertaining whether or not the parcel was occupied, and the
name and residence of the occupant, if any, and that in every case where
those parcels of land were found to be occupied, upon such investigation,
the name of the occupant is stated in the commissioners' report opposite
that parcel, together with his residence, when ascertained. Such an
affidavit and report shall be prima facie evidence that the requirements of
this Division 2 have been complied with.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-24) (from Ch. 24, par. 9-2-24)
Sec. 9-2-24.
Every person who is named in the commissioners' report as an
owner of property to be taken or damaged for the improvement, and every
person who is therein named as an occupant of any parcel thereof, shall be
made a party defendant in the proceeding. All other persons having or
claiming interest in any of the premises shall be described and designated
as "all whom it may concern," and by that description shall be made
defendants. Upon the filing of the commissioners' report, a summons shall
be issued and served upon the persons made party defendants, as in other
civil actions, except that the summons shall require a defendant to appear
within 15 days after service, exclusive of the day of service. As to such
of the defendants as are shown by the affidavits to be non-residents of the
State of Illinois, or whose residences are shown thereby to be unknown, and
the defendants designated as "all whom it may concern," the clerk of the
court shall publish in one or more newspapers published in the
municipality, or, if no newspaper is published therein, then in one or more
newspapers with a general circulation within the municipality, a notice of
the pendency of the proceeding, the parties thereto, the title of the
court, the time and place of the return of the summons in the case, the
description of the property to be taken or damaged, the total cost of the
improvement as shown by the estimate and report, and the nature of the
proceeding. This notice shall further state that a special assessment has
been made to raise the cost of the improvement, and the time and place of
filing the report thereof. This notice shall be published at least once in
each week for 3 weeks, the first notice to be published at least 30 days
before the return day of the summons.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-25) (from Ch. 24, par. 9-2-25)
Sec. 9-2-25.
Where the residence of any defendant named in the
commissioners' report is shown thereby to be outside of the State of
Illinois, and the residence is stated therein, a copy of the specified
notice shall be sent by mail to that party, at the address so given, at
least 15 days prior to the return day of the summons. If the residence of
any defendant is found to be unknown, as shown by the report and affidavit,
a similar notice shall be sent to the person last paying taxes upon the
premises, if his residence is stated in the report. Such service,
publication, and notices shall be sufficient to give the court jurisdiction
of all the parties whose land is to be taken or damaged, so as to determine
all questions relating to the proceeding, and affecting the land described
in the report.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-26) (from Ch. 24, par. 9-2-26)
Sec. 9-2-26.
There shall be sent by mail, post paid, to each of the persons
paying the taxes during the last preceding year in which taxes were paid on
the property which has been assessed for the benefits in the proceeding,
directed to the address as shown in the commissioners' report, or where not
so shown, then generally to the municipality in which the improvement is to
be made, at least 15 days before the specified return day, a notice stating
the nature of the improvement, the description of that taxpayer's property
assessed therefor, the amount of the assessment, and the date when the
summons in the cause will be returnable, and when objections thereto may be
filed. An affidavit of one of the commissioners, or some other person
showing such service, mailing, posting, and publication, shall be prima
facie evidence of a compliance with all the requirements thereof, but the
publication may be proved in any other manner provided by law.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-27) (from Ch. 24, par. 9-2-27)
Sec. 9-2-27.
Upon the return of the summons, or as soon thereafter as the
business of the court will permit, the court shall proceed to a hearing of
the cause, and shall impanel a jury to ascertain the just compensation to
be paid to all owners of property to be taken or damaged. If objections are
filed to the confirmation of the assessment of benefits, those objections
shall be submitted to the same jury at the same time. Thereupon the jury
shall ascertain the just compensation to be paid to the owner of each lot,
block, tract, or parcel of land to be taken or damaged in the proceeding,
and shall also determine whether or not any lot, piece, or parcel of land
assessed in the proceeding, for which objections have been filed, has been
assessed more than it will be benefited by the improvement. On this hearing
the commissioners' report so returned and filed, shall be prima facie
evidence, both of the amount of the compensation to be awarded, and of the
benefits to be assessed, but either party may introduce such other evidence
as may bear upon that issue or issues.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-28) (from Ch. 24, par. 9-2-28)
Sec. 9-2-28.
If any defendant or party interested demands, and if the court
deems it proper, separate juries may be impaneled, either as to the
benefits assessed, or as to the compensation or damages to be paid to any
one or more of the defendants or parties in interest.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-29) (from Ch. 24, par. 9-2-29)
Sec. 9-2-29.
The court upon the motion of the petitioner, or of any person
claiming any such compensation, may direct that the jury, under the charge
of an officer, shall view the premises which it is claimed by any party to
the proceeding will be taken or damaged by the improvement. In any case
where there is no satisfactory evidence given to the jury as to the
ownership of, or as to the extent of the interest of any defendant in, the
property to be taken or damaged, the jury may return their verdict as to
the compensation or damage to be paid for the property or part of property
to be taken or damaged, and for the entire interests therein.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-30) (from Ch. 24, par. 9-2-30)
Sec. 9-2-30.
Upon the return of the jury's verdict, the court shall order
the verdict to be recorded and shall enter such judgment thereon
as the nature of the case may require. The court shall continue or adjourn
the cause from time to time as to all occupants and owners named in the
petition who have not been served with process, or brought in by notice or
by publication, and shall order a new summons to issue and publication to
be made. When those occupants or owners are brought into court, the court
shall impanel a jury to ascertain the compensation to be paid to those
defendants for property taken or damaged, and the amount of benefits to be
assessed against them, if any. Like proceedings shall be had for that
purpose as hereinbefore provided in the case of other owners. But no final
judgment shall be entered as to any of the property embraced in the
assessment roll until all the issues in the case have been disposed of,
including revised rolls, if any.
(Source: P.A. 84-452; 84-545)
(65 ILCS 5/9-2-31) (from Ch. 24, par. 9-2-31)
Sec. 9-2-31.
Upon proof that any owner named in such petition, who has not
been served with process, has ceased to own the described property since
the filing of the petition, the court has the power, at any time, to
impanel a jury and ascertain the just compensation to be made for that
property, or the damage thereto, and the benefits thereto. Upon any finding
or findings of the jury, or at any time during the course of the
proceedings, the court may enter such order, rule, or judgment as
the nature of the case may require.
(Source: P.A. 79-1361.)
(65 ILCS 5/9-2-32) (from Ch. 24, par. 9-2-32)
Sec. 9-2-32.
No delay in making an assessment of compensation shall be
occasioned by any doubt or contest which may arise as to the ownership of
the property or any part thereof, or as to the interests of the respective
owners or claimants. In case of such a doubt or contest the court may
require the jury to ascertain the entire compensation or damage that should
be paid for the property, or part of the property, and the entire interests
of all parties therein, and may require adverse claimants to interplead, so
as to fully determine their rights and interests in the compensation so
ascertained. And the court may make such order as may be necessary in
regard to the deposit or payment of that compensation.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-33) (from Ch. 24, par. 9-2-33)
Sec. 9-2-33.
When it appears from the petition, or otherwise at any time
during the proceedings upon the petition, that any minor or person under
legal disability is interested in any property
that is to be taken or
damaged, the court shall appoint a guardian ad litem for that person, to
defend his or her interest in that property, or the compensation which is awarded
therefor.
(Source: P.A. 83-706.)
(65 ILCS 5/9-2-34) (from Ch. 24, par. 9-2-34)
Sec. 9-2-34.
Any final judgment rendered by a court upon any finding of any
jury or of any judge where trial by jury is waived by the parties
concerned, shall be a lawful and sufficient condemnation of the land or
property to be taken, upon the payment of the net amount of the finding, as
hereinafter provided. It shall be final and conclusive as to the damages
and benefits caused by the improvement, unless the judgment is appealed
from. But no appeal shall delay proceedings under the ordinance, if the
petitioner files in the case its written election to proceed with the
improvement notwithstanding that appeal and deposits, as directed by the
court, the amount of judgment and costs, after deducting the benefits
assessed and adjudged against that property, if any. If the petitioner so
elects to make such a deposit prior to the final determination of any
appeal, it shall thereby become liable to pay to the owners of and parties
interested in the property in question, the difference, if any, between the
amount so deposited and the amount ultimately adjudged to be the just
compensation to be paid on account of the property, and interest on any
such difference at the rate of 5% annually from the date of the making of
the deposit, and costs.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-35) (from Ch. 24, par. 9-2-35)
Sec. 9-2-35.
The court, upon proof that the amount of the just compensation
as found by the jury or by the court in case a trial by jury is waived by
the parties concerned, in excess of the benefits so assessed and adjudged
against the same property, has been paid to the person entitled thereto, or
has been deposited as directed by the court, shall enter an order that the
petitioner has the right, at any time thereafter, to take possession of or
damage the property, in respect to which compensation has been so paid or
deposited.
(Source: P.A. 79-1361.)
(65 ILCS 5/9-2-36) (from Ch. 24, par. 9-2-36)
Sec. 9-2-36.
Upon the return of a verdict in a proceeding to acquire
property for a public improvement, if no motion for a new trial is made, or
if made, is overruled, the petitioner, within 90 days after final judgment
as to all defendants, both as to the amount of damages and compensation to
be awarded and benefits to be assessed shall elect whether it will dismiss
the proceeding or enter judgment on the verdict. If it elects to enter
judgment on the verdict, it shall become bound thereby and liable to pay
the amount thereof, whether the assessment is collected or not, and the
judgment of condemnation shall not be conditional. But the judgment shall
not draw interest until the petitioner takes possession of or damages the
property, in respect to which the judgment is entered. After entry of
judgment the petitioner shall not be permitted to withdraw from or to
dismiss the proceeding, without the consent of all parties whose land is
thereby condemned, except as hereinafter provided. In case an appeal is
taken by either party from the judgment of condemnation or confirmation,
then unless the petitioner files in the cause its written election to
proceed with the improvement notwithstanding the appeal, no steps shall be
taken to collect the assessment nor to compel payment of the compensation
awarded until the appeal is disposed of and final judgment entered in the
cause, or, in case of reversal, until there is a new trial and judgment.
However, in case of a final reversal the petitioner may still elect, within
a period of 60 days, to abandon the proceeding.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-37) (from Ch. 24, par. 9-2-37)
Sec. 9-2-37.
If, in any case, upon the filing of the assessment roll by the
commissioners, it appears that the amount assessed as benefits is not
sufficient to pay the awards, with the costs, or if, upon the disposition
of the whole case, any such deficiency appears, the court, on the
application of the petitioner, may refer the roll again to the same or
other commissioners, to be recast. In such cases the commissioners shall
consider and report whether or not other premises will be benefited by the
improvement, or whether or not the premises already assessed will be
benefited thereby in any greater amount, and in what amount, if any, and
shall make and return a revised assessment roll. This may be done from time
to time, as often as any deficiency appears. But no lot, block, tract, or
parcel of land shall be assessed more than it will be benefited by the
improvement, nor more than its proportionate share of the costs of the
improvement. If any premises not already described in the roll are assessed
by the commissioners, the owners thereof shall be shown and notice given as
for an original assessment. If the assessment on any premises previously
assessed is increased thereby, or if any property is newly assessed, the
owner thereof, if not already represented in court, shall be notified in
like manner, and a hearing shall be had as above provided.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-38) (from Ch. 24, par. 9-2-38)
Sec. 9-2-38.
Any municipality which (1) has a population exceeding
15,000 but less than 500,000, (2) is not located within any sanitary
district, (3) discharges its sewage into Lake Michigan without having
provided any adequate provisions for otherwise disposing of its sewage,
and (4) owns and operates a waterworks and sewerage system, the cost of
the construction of which waterworks and sewerage system has been
provided for by special assessment, and a large portion of which cost
has been assessed against the municipality for public benefits, has the
power to provide by ordinance for the levy, in addition to the taxes now
authorized by law, and in addition to the amount authorized to be levied
for general purposes as provided by Section 8-3-1, of a direct annual
tax for not exceeding 20 successive years and not exceeding .1666% of
the value, as equalized or assessed by the Department of Revenue of all
taxable property, in the municipality. This
tax shall be levied and collected with and in like manner as the general
tax in the municipality and shall be known as the public benefit tax.
The fund arising therefrom shall be known as the public benefit fund,
which fund shall be used solely for the purpose of paying that portion
of the several amounts heretofore assessed against the municipality for
such public benefits, as well as for paying any such amounts as may be
hereafter so assessed for such public benefits under and in pursuance of
any ordinance that may be hereafter passed. However, no such tax shall
be levied in excess of .1% of the taxable property for any year until
after the corporate authorities of the municipality have passed an
ordinance providing for the levying of that excess. This ordinance shall
not become effective until it has been submitted to the electors of the
municipality in accordance with the provisions of Sections 8-4-1 and
8-4-2 and has been approved by a majority of the electors voting upon
the question.
Where any such tax has been levied, warrants may be drawn against the
tax in the manner and with like effect as is provided by Sections 8-1-9,
8-1-11 and 8-1-12.
This section is subject to the provisions of the General Revenue Law
of Illinois.
(Source: P.A. 81-1509.)
(65 ILCS 5/9-2-39) (from Ch. 24, par. 9-2-39)
Sec. 9-2-39.
Any municipality having a population of less than
500,000 may provide by ordinance for the levy, in addition to the taxes
now authorized by law, and in addition to the amount authorized to be
levied for general purposes as provided by Section 8-3-1, of a direct
annual tax not exceeding .05%, or the rate limit in effect on July 1,
1967, whichever is greater, of the value, as equalized or assessed by
the Department of Revenue, of all taxable property in
the municipality. This tax shall be known as the public benefit tax. The
fund arising therefrom shall be known as a public benefit fund, which
fund shall be used solely for the purpose of paying that portion of the
several amounts heretofore assessed against the municipality for public
benefit as well as paying any such amounts as may be hereafter assessed
for public benefit under and in pursuance of any ordinance that may be
hereafter passed. However, where and whenever any road or street is
constructed or reconstructed by the State or any county or both jointly
with any municipality, the municipality may consider, accept, and use,
the amount estimated by the State of Illinois or the county, or both, to
be its or their portion of the cost of construction, as a part or all of
the municipal public benefit.
Where any such tax has been so levied, warrants may be drawn against
the tax, as and in the manner and with like effect as is provided by
Sections 8-1-9, 8-1-11 and 8-1-12. The foregoing limitations upon tax
rates may be increased or decreased under the referendum provisions of
the General Revenue Law of Illinois.
(Source: P.A. 81-1509.)
(65 ILCS 5/9-2-40) (from Ch. 24, par. 9-2-40)
Sec. 9-2-40.
Whenever the owners of one-half of the property abutting on
any street, alley, park, or public place, or portion thereof, petition for
any local improvement thereon, the board of local improvements in any
municipality shall take steps hereinbefore required for hearing thereon,
but at that hearing shall consider only the nature of the proposed
improvement and the cost thereof. The board shall determine, in the manner
above provided, the nature of the improvement which it will recommend, and
thereupon shall prepare and transmit to the corporate authorities a draft
of an ordinance thereof, together with an estimate of the cost, as above
described, and shall recommend the passage thereof. Such a recommendation
shall be prima facie evidence that all the preliminary steps required by
law have been taken. Thereupon it is the duty of the corporate authorities
to pass an ordinance for that improvement and to take the necessary steps
to have the ordinance carried into effect.
Whenever an ordinance provides only for the building or renewing of any
sidewalk, and the owner of any lot or piece of land fronting on that
sidewalk builds or renews that sidewalk opposite to his land to conform in
all respects to the requirements of that ordinance within 40 days after the
ordinance takes effect, an allowance shall be made in the spreading of the
assessment against that lot or piece of land of an amount equal to the
estimated cost of that sidewalk, based on the cost per unit of the sidewalk
as shown in the engineer's estimate.
Notice of the passage of such a sidewalk ordinance shall be sent by mail
within 10 days after the ordinance takes effect to the person who paid the
taxes on the premises for the last preceding year, in which taxes were
paid, if he can be found in that county. A like notice addressed to the
occupant of the property, if the property is actually occupied at that
time, and an affidavit of such service shall be filed with the official
report of the assessment. Such an affidavit shall be prima facie evidence
of a compliance with these requirements.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-41) (from Ch. 24, par. 9-2-41)
Sec. 9-2-41.
When the ordinance under which a local improvement is ordered
provides that the improvement shall be made wholly or in part by special
taxation of contiguous property, that special tax shall be levied,
assessed, and collected, as nearly as may be, in the manner provided in the
section of this Division 2 providing for the mode of making, assessing, and
collecting special assessments. No special tax shall be levied or assessed
upon any property to pay for any local improvement in an amount in excess
of the special benefit which the property will receive from the
improvement. The ordinance shall not be deemed conclusive of the benefit,
but the question of the benefit and of the amount of the special tax shall
be subject to the review and determination of the court, and shall be tried
in the same manner as in proceedings by special assessment.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-42) (from Ch. 24, par. 9-2-42)
Sec. 9-2-42.
When the ordinance under which a local improvement is ordered
to be made contains no provisions for the condemnation of private property
therefor, and provides that the improvement shall be wholly or in part paid
for by special assessment, the proceedings for the making of that
assessment shall be as follows.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-43) (from Ch. 24, par. 9-2-43)
Sec. 9-2-43.
Upon the passage of any ordinance for a local improvement
pursuant thereto, the officer specified therein shall file a petition in
the circuit court in the county where the affected territory lies, or if
the municipality is situated in more than one county and the proposed
improvement lies in more than one county, then in the circuit court in the
county in which the major part of the territory to be affected thereby is
situated, in the name of the municipality, praying that steps be taken to
levy a special assessment for the improvement in accordance with the
provision of that ordinance. There shall be attached to or filed with this
petition a copy of the ordinance, certified by the clerk under the
corporate seal, and also a copy of the recommendation of the board of local
improvements and of the estimate of cost as approved by the corporate
authorities. The failure to file any or either of these copies shall not
affect the jurisdiction of the court to proceed in the cause and to act
upon the petition, but if it appears in any such cause that the copies have
not been attached to or filed with the petition before the filing of the
assessment roll therein, then, upon motion of any objector for that purpose
on or before appearance day in the cause the entire petition and
proceedings shall be dismissed.
The several circuit courts of this State have jurisdiction of any
proceeding under this Division 2.
(Source: Laws 1967, p. 3762.)
(65 ILCS 5/9-2-44) (from Ch. 24, par. 9-2-44)
Sec. 9-2-44.
Upon the filing of such a petition, either the superintendent
of special assessments, in municipalities where that officer is provided
for by law or some competent person appointed by the president of the board
of local improvements in municipalities where the office of such
superintendent does not exist, shall make a true and impartial assessment
of the cost of the specified improvement upon the petitioning municipality
and the property benefited by the improvement.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-45) (from Ch. 24, par. 9-2-45)
Sec. 9-2-45.
The officer specified in Section 9-2-44 shall estimate what
proportion of the total cost of such improvement will be of benefit to the
public, and what proportion thereof will be of benefit to the property to
be benefited, and to apportion the total cost between the municipality and
that property, so that each will bear its relative equitable proportion.
Having found these amounts, such officer shall apportion and assess the
amount so found to be of benefit to the property, upon the several lots,
blocks, tracts, and parcels of land, in the proportion in which they will
be severally benefited by the improvement. No lot, block, tract, or parcel
of land shall be assessed a greater amount than it will be actually
benefited, except that the apportionment and assessment shall include the
anticipated fees for the recording of documents as provided in this
Article. When the proposed improvement is for the construction of a
sewer, it is the duty of such officer to investigate and report the
district which will be benefited by the proposed sewer, describing the
district by boundaries.
Where the improvement is to be constructed with aid from any agency of
the Federal Government, or other governmental agency, the proportion of the
total cost of the improvement to be raised by the municipality in addition
to such aid shall be the amount allocated between public benefits and
benefits of the property affected as above provided.
(Source: P.A. 85-1252.)
(65 ILCS 5/9-2-46) (from Ch. 24, par. 9-2-46)
Sec. 9-2-46.
In levying any special assessment or special tax, each lot,
block, tract, or parcel of land shall be assessed separately, in the same
manner as upon assessment for general taxation. However, this requirement
shall not apply to the property of railroad companies, or the right of way
and franchise of street railway companies. Such property and right of way
and franchise may be described in any manner sufficient to reasonably
identify the property intended to be assessed.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-47) (from Ch. 24, par. 9-2-47)
Sec. 9-2-47.
The assessment roll shall contain (1) a list of all the lots,
blocks, tracts, and parcels of land assessed for the proposed improvement and,
in counties in which a property index number system has been established in
accordance with Section 9-45 of the Property Tax Code, the index number in
addition to the legal description, (2) the amount assessed against each, (3)
the name of the person who paid the taxes on each such parcel during the last
preceding calendar year in which taxes were paid, as ascertained upon
investigation by the officer making the return, or under his direction, and (4)
the residence of the person so paying the taxes on each such parcel if the
residence on diligent inquiry can be found. In case of an assessment in
installments, the amount of each installment shall also be stated. The officer
making the roll shall certify under oath that he believes that the amounts
assessed against the public and each parcel of property are just and equitable,
and do not exceed the benefit which in each case will be derived from the
improvements, and that no lot, block, tract, or parcel of land has been
assessed more than its proportionate share of the cost of the improvement.
Several lots, or parts of land, owned and improved as one parcel may be
assessed as one parcel.
Notice shall be given of the nature of the improvement, of the pendency
of the proceeding, of the time and place of filing the petition therefor,
of the time and place of filing the assessment roll therein, and of the
time and place at which application will be made for confirmation of the
assessment, the same to be not less than 15 days after the mailing of such
notices. The notices shall be sent by mail postpaid to each of the
specified persons paying the taxes on the respective parcels during the
last preceding year in which taxes were paid, at his residence as shown in
the assessment roll, or, if not shown, then to such person so paying the
taxes, directed generally to the municipality in which the improvement is
proposed to be made.
The notice shall state the amount assessed to the person to whom it is
directed for the improvement proposed, the total amount of the cost of the
improvement, and the total amount assessed as benefits upon the public.
Where the improvement is to be constructed with aid furnished by any
agency of the Federal Government, or other governmental agency, the notice
shall set forth, in dollars and cents, the estimated amount of aid to be so
furnished.
An affidavit shall be filed before the final hearing showing a
compliance with the requirements of this section, and also showing that the
affiant, either the officer making the specified return, or some one acting
under his direction, made a careful examination of the collector's books
showing the payments of general taxes during the last preceding year in
which the taxes were paid thereon, to ascertain the person who last paid
the taxes on the respective parcels, and a diligent search for his
residence, and that the report correctly states the persons and residences
as ascertained by the affiant. This report and affidavit shall be
conclusive evidence, for the purpose of this proceeding, of the correctness
of the assessment roll in these particulars. In case the affidavit is found
in any respect wilfully false, the person making it is guilty of perjury,
and upon conviction thereof shall be punished according to the laws of this
State.
(Source: P.A. 88-670, eff. 12-2-94.)
(65 ILCS 5/9-2-48) (from Ch. 24, par. 9-2-48)
Sec. 9-2-48.
The corporate authorities may provide in the ordinance for
any local improvement, any portion of the cost of which is to be defrayed
by special assessment or special taxation, or by ordinance passed at any
time before the confirmation of the assessment roll, that the aggregate amount
assessed, and each individual assessment, and also the assessment against
the municipality on account of property owned by the municipality and for
public benefits be divided into installments not more than 10 in number.
However, any such special assessment or special tax levy for building
sewers or viaducts or for the acquisition, construction, and operation or
maintenance of a pedestrian mall and parking facilities for a commercial
or shopping center, notwithstanding the provisions of Division 71 of
Article 11 of the "Illinois Municipal Code", approved May 29, 1961, as
amended, provided that the owners of a majority of the property abutting on
any street, alley, park or public place or portion thereof within such
commercial or shopping center area shall consent to such assessment and
further provided that no such assessment as above authorized shall be made
against a property used wholly for residential purposes, in like manner may
be divided into not exceeding 20 installments, and any such special
assessment or special tax levy for building subways may in like manner be
divided into not exceeding 40 installments. In all cases such a division
shall be made so that all installments shall be equal in amount, except
that all fractional amounts shall be added to the first installment, so as
to leave the remaining installments of the aggregate equal in amount and
each a multiple of $100. The first installment shall be due and payable on
January 2 next after the date of the first voucher issued on account of
work done, and the second installment one year thereafter, and so on
annually until all installments are paid. The board of local improvements
shall file in the office of the clerk of the court in which such an
assessment was confirmed, a certificate signed by its secretary, of the
date of the first voucher and of the amount thereof, within 30 days after
the issuance thereof.
All installments shall bear interest as hereinafter provided until paid,
at the rate set forth in the ordinance referred to in Section 9-2-10 of
the Illinois Municipal Code and not to exceed the greater of (i) 9% annually
or 70% of the Prime Commercial Rate in effect at the time of the passage
of such ordinance or (ii) the maximum rate authorized by the Bond
Authorization Act, as amended at the time of the making of the contract.
Interest on assessments shall
begin to run from 60 days after the date of the first voucher issued on
account of work done, except as otherwise provided in Section 9-2-113. The
interest on each installment shall be payable as follows: on January 2 next
succeeding the date of the first voucher as certified, the interest accrued
up to that time on all unpaid installments shall be due and payable and be
collected with the installment, and thereafter the interest on all unpaid
installments then payable, shall be payable annually and be due and payable
at the same time as the installments maturing in that year and be collected
therewith. In all cases the municipal collector, whenever payment is made
of any installment, shall collect interest thereon up to the date of such
payment whether the payment be made at or after maturity. Any person may at
any time pay the whole assessment against any lot, piece, or parcel of
land, or any installment thereof with interest as provided in this Division
2 up to the date of payment. Whenever any municipality heretofore has
levied for any public improvement a special tax or a special assessment
payable in not to exceed 10 installments of which all except the first draw
interest at any rate specified in the ordinance under the authority of
which the improvement is made, and judgment has
been duly entered in the proceeding confirming the tax or the assessment so
payable, the judgment in that proceeding shall not be invalid because the
assessment is so divided or because the rate of interest therein is fixed
at an interest rate of less than that set forth in said ordinance,
but all such judgments, unless void
for other reasons, shall be valid and enforceable. And when improvement
bonds have been issued for the purpose of anticipating the collection of
the deferred installments of any such special tax or assessment, the bonds,
if otherwise valid, shall not be void either because of the number of
series into which they are divided or the rate of interest they bear. If
the bonds are in other respects in compliance with the statutes of the
State of Illinois in such cases, they shall be valid and enforceable to the
extent that the tax or assessment against which they are levied is
enforceable or any re-levy thereof.
The cost of operating and maintaining any pedestrian mall and parking
facilities for a commercial or shopping center as provided for herein may
be assessed not more than once in each calendar year against all property
in a benefited area.
Any municipality which has provided or does provide for the creation of
a plan commission under Division 12 of Article 11 shall submit to and
receive the approval of the plan commission before establishing,
maintaining or operating any such pedestrian mall and parking facilities
for a commercial or shopping center.
With respect to instruments for the payment of money issued under this
Section either before, on, or after the effective date of this amendatory
Act of 1989, it is and always has been the intention of the General
Assembly (i) that the Omnibus Bond Acts are and always have been
supplementary grants of power to issue instruments in accordance with the
Omnibus Bond Acts, regardless of any provision of this Act that may appear
to be or to have been more restrictive than those Acts, (ii) that the
provisions of this Section are not a limitation on the supplementary
authority granted by the Omnibus Bond Acts, and (iii) that instruments
issued under this Section within the supplementary authority granted
by the Omnibus Bond Acts are not invalid because of any provision of
this Act that may appear to be or to have been more restrictive than
those Acts.
This amendatory Act of 1971 is not a limit upon any municipality which
is a home rule unit.
This amendatory Act of 1972 is not a limit upon any municipality which
is a home rule unit.
(Source: P.A. 86-4.)
(65 ILCS 5/9-2-48(1)) (from Ch. 24, par. 9-2-48(1))
Sec. 9-2-48(1).
In addition to any other powers or procedures for the
making of a local improvement by special tax or assessment, when a
pedestrian mall and parking facilities improvement is proposed or made
under Section 9-2-48, the corporate authorities may provide in the original
ordinance for the improvement, or in a separate ordinance, that the costs
and expenses of maintenance and operation thereof as provided in this
Section shall be paid for by an annual assessment, upon the commercial or
business property within the district of the improvement, which improvement
district is primarily benefited by the provision for such costs and
expenses which are necessary, convenient and desirable for the protection
and preservation of the capital improvement so made and the operation,
upkeep, repairs, replacement and/or maintenance of the said improvement and
its component parts, fixtures, equipment or facilities. When an ordinance
is so enacted, the annual assessment so provided for by such ordinance may
be made under and in accordance with the provisions of this Section.
(a) The annual assessment hereunder shall be made each year for a
period of consecutive years not exceeding the number of years over which
the cost for the making of the improvement has been spread, provided,
however, that by consent of the owners of 66 2/3% of the frontage of
private property within the district, the annual assessment can be
continued for additional periods of years.
The annual assessments hereunder shall be due and payable on January
2nd next after the date of confirmation of each annual assessment.
(b) Upon the completion of the pedestrian mall or parking facility,
the court in which the special assessment or tax for the making of the
improvement was confirmed shall upon the application of the municipality
or any assessee within the district, appoint a board of commissioners
consisting of 5 members, at least 3 of whom shall be
owners or lessees (or their duly authorized representatives) of property
within the district. The board of commissioners shall determine and
estimate the amount of the costs and expenses of the improvement for the
year as provided in this Section, and shall file a report of said
expenses and an assessment roll signed and certified to by the chairman
of the board, spreading the total annual cost over the property of the
district proportionate to the assessed valuation of said property for
general real estate tax purposes. Notice of the filing of said report
and assessment shall be given to the assessee of taxes for said property
and a date for filing and hearing objections, if any, thereto shall be
set. The court shall hear and determine objections and shall have full
and complete power to revise, confirm, modify, amend or recast the said
roll to comply with the provisions of this Section, including the power
to revise individual assessments wherein the assessment as levied in
accordance with this Section exceeds the benefit to the property or
constitutes more than a proportionate share of the total annual
assessment. Upon confirmation of the roll and the annual assessment, a
warrant to collect the assessment shall issue by the County Clerk. The
assessment hereunder shall have the same force and effect as other
assessments under Article 9 Division 2 and shall be otherwise governed
thereby except as provided otherwise herein. The annual assessments
collected hereunder shall be paid over to the board of commissioners who
shall apply same in discharge of the actual cost and expenses provided
for herein as incurred during the course of said year. Any surplus in
the estimated amount collected over the actual costs or expense of the
year shall be credited on the next year's estimate and any deficiency
shall be included as a permitted item of cost or expense to be defrayed
by the assessment for the following year. In the event there is any
surplus of assessments collected in the last year of collections, the
same shall be rebated in proportion to the assessments for that year,
and in the event there is any deficiency in collections of the last
year, a final winding-up assessment to satisfy said deficit shall be
made for the year following the said last year of assessment hereunder.
(c) The items of cost and expense which may be included in the
estimate and for which an annual assessment may be levied hereunder are
as follows:
1. The cost of repairs, upkeep and maintenance of any or all
fixtures, equipment or facilities which comprised the improvement as
originally made or any replacements thereof.
2. The costs of repairs, upkeep and maintenance of any common areas
within the improvement as originally made.
3. The costs of any additions to or modifications of the improvement
as originally made, any new or additional fixtures, equipment,
facilities or service which is or are determined to be essential to
public health, safety or welfare and to the protection and
preservation of the improvement and the operation thereof.
4. A reserve for contingencies in the item of costs and expense
estimated, not to exceed 10% of the total of such costs for the year
in question.
5. A reserve to defray interest on funds borrowed or vouchers issued
in anticipation of collection of annual installments.
6. Any deficiencies in collection over the actual costs and expense
of the preceding year.
7. The costs and expenses of management employees and facilities, of
making and levying the assessments and letting and executing
contracts, of necessary estimates, examinations, advertisements and
the like, including any court costs and fees, and for reimbursement
of the expenses incurred by the commissioners in performing their
duties hereunder.
(d) The commissioners to be appointed hereunder shall receive no
compensation for services and shall serve for a term of 5, 4, 3, 2 and 1
year from the date of appointment and the term shall be selected by lot
at the first meeting of the board after appointment by the court. The
court shall thereafter appoint commissioners for 5 year terms
upon termination of each term and shall appoint successors in the event
of vacancy. Any commissioner shall be eligible to succeed himself.
(e) The board of commissioners shall have authority:
(1) To issue vouchers in anticipation of the collections of the
annual assessments, in payment for the costs and expenses of
maintenance and operation provided for hereunder and such vouchers
shall be payable from the annual assessments when collected and shall
bear interest at a rate set by the board, not to exceed the greater of
9% or 70% of the Prime Commercial Rate in effect at the time of the passage
of the ordinance referred to in Section 9-2-10 of the Illinois Municipal
Code.
(2) To borrow funds for working capital in anticipation of collection
of annual assessments at a rate of interest not to exceed the greater
of (i) 9% annually or 70% of the Prime Commercial Rate in effect at the time
of the passage of the ordinance referred to in Section 9-2-10 of the Illinois
Municipal Code or (ii) the maximum rate authorized by the Bond
Authorization Act, as amended at the time of the making of the contract.
(3) To enter into agreements with the municipality relative to the
payment of that portion of the costs of maintenance and operation
provided for herein, which reflects the general public benefit
derived from the protection and preservation of the pedestrian mall
or parking facility improvement. In such agreements, the board shall
have authority to accept the fair and reasonable value of service
provided by the municipality in full or partial satisfaction of the
public benefit portion of said costs.
With respect to instruments for the payment of money issued under this
Section either before, on, or after the effective date of this amendatory
Act of 1989, it is and always has been the intention of the General
Assembly (i) that the Omnibus Bond Acts are and always have been
supplementary grants of power to issue instruments in accordance with the
Omnibus Bond Acts, regardless of any provision of this Act that may appear
to be or to have been more restrictive than those Acts, (ii) that the
provisions of this Section are not a limitation on the supplementary
authority granted by the Omnibus Bond Acts, and (iii) that instruments
issued under this Section within the supplementary authority granted
by the Omnibus Bond Acts are not invalid because of any provision of
this Act that may appear to be or to have been more restrictive than
those Acts.
(Source: P.A. 86-4.)
(65 ILCS 5/9-2-49) (from Ch. 24, par. 9-2-49)
Sec. 9-2-49.
Whenever an ordinance provides for the making of a local
improvement which comprises either the construction of an improvement or
the taking or damaging of property therefor, or both such construction and
taking or damaging, and proceedings are instituted prior to, on or after
January 1, 1942, for the confirmation of a special assessment or a special
tax to defray the whole or any portion of the cost of any such improvement,
including the cost of the construction thereof and the compensation for the
taking or damaging of property therefor, or including only the cost of
taking or damaging of property therefor, and including in each such
proceeding the cost of making and collecting the special assessment or
special tax (in the case of such municipalities as may lawfully include
that cost in special assessment or special tax proceedings), the corporate
authorities may provide by the ordinance for any such local improvement, or
if proceedings authorized by any such ordinance have been filed in court,
then by an ordinance passed at any time before the confirmation of the
assessment roll filed in any such proceeding, that the aggregate amount
assessed to defray the cost of the improvement, including the cost of the
construction thereof and the compensation for the taking or damaging of
property therefor or including only the cost of taking or damaging property
therefor, and each individual assessment and also the assessment against
the municipality on account of property owned by the municipality and for
public benefits, be divided into not more than 20 installments. Such
installments shall be equal in amount and each a multiple of $100, except
that any fractional amounts of the aggregate assessment, after division as
aforesaid, shall be apportioned to the first installment. However, if it is
so provided by ordinance passed at any time before the confirmation of the
assessment roll, so much of the aggregate amount assessed as represents the
cost of the construction of the improvement shall be divided into as many
parts as there are installments, which parts shall be equal in amount and
each a multiple of $100, except that any fractional amounts of the cost of
construction after division as aforesaid shall be apportioned to the first
installment, and so much of the aggregate amount assessed as represents the
compensation for property to be taken or damaged, together with the cost of
making and collecting the special assessment or special tax (in the case of
such municipalities as may lawfully include that cost in special assessment
or special tax proceedings) shall be apportioned to the first installment
of the special assessment or special tax.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-50) (from Ch. 24, par. 9-2-50)
Sec. 9-2-50.
Within 30 days after the entry of confirmation of the
assessment roll in such a proceeding described in Section 9-2-49, the clerk
of the court in which the judgment is rendered shall certify the assessment
roll and judgment to the officer of the municipality authorized to collect
the special assessment or tax. If, however, there has been an appeal taken
on any part of the judgment, then the designated clerk shall certify such
part of the judgment as is not included in that appeal and this
certification shall be filed by the officer receiving it, in his office.
With the assessment roll and judgment, the clerk of the specified court
shall also issue and deliver a warrant for the collection of the assessment
or tax. Upon the delivery of this warrant to the designated collecting
officer, the first installment of such assessment or tax shall be
immediately due and payable. The second installment of the assessment or
tax shall be due and payable on the second day of January next after the
date of the first voucher issued on account of work done, if the
uncollected portion of the first installment has been returned delinquent
to the authorized county officer as provided in this article, but if the
same has not been so returned delinquent, then the second installment shall
be due and payable one year after that second day of January. The third and
subsequent installments shall be due and payable respectively at successive
annual periods after the second installment becomes due and payable. The
amount awarded to any person for property taken or damaged may be applied,
at the option of the owner of that property, as an offset to the amount of
benefits assessed in the first and succeeding installments against any
property owned by that person and assessed in that proceeding.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-51) (from Ch. 24, par. 9-2-51)
Sec. 9-2-51.
All installments established pursuant to Section 9-2-50
shall bear in Section 9-2-10 of the Illinois Municipal Code and not more
than the greater of (i) 9% annually or 70% of the Prime Commercial Rate in
effect at the time of the passage of such ordinance, or (ii) the maximum
rate authorized by the Bond Authorization Act, as amended at the time of
the making of the contract, payable annually, and such interest shall begin
to run from 60 days after the date when the first installment becomes due
and payable. Interest on the first installment, if any, shall be due and
payable and shall be collected at the same time as the first installment.
Interest on the second and subsequent installments, if any, shall be due
and payable and shall be collected with the installments respectively, as
provided in this Division 2. Bonds to anticipate the collection of the
installments of the assessment provided for in this Section may be issued
after the entry of confirmation in any such proceeding, and such bonds
shall draw interest from the date of issuing the same at the rate specified
in said ordinance referred to in Section 9-2-10 and of not more than the
rate the installments of the assessment against which the bonds are being
issued bear, payable annually, and shall otherwise conform to the
provisions of Section 9-2-119 or Sections 9-2-127 through 9-2-129.
The special assessment or special tax described in Section 9-2-49 shall
be collected in the manner prescribed in this Division 2 for other special
assessments and special taxes, except that the collection of the first
installment of such special assessment or special tax, or any part thereof,
may be enforced if necessary by the sale of the property against which the
same is levied, notwithstanding that the improvement for which the same is
levied may not have been completed.
The proceedings provided for in this Section also shall be governed by
the other Sections of this Division 2 so far as they are applicable
thereto, and not inconsistent with the provisions of this Section.
With respect to instruments for the payment of money issued under this
Section either before, on, or after the effective date of this amendatory
Act of 1989, it is and always has been the intention of the General
Assembly (i) that the Omnibus Bond Acts are and always have been
supplementary grants of power to issue instruments in accordance with the
Omnibus Bond Acts, regardless of any provision of this Act that may appear
to be or to have been more restrictive than those Acts, (ii) that the
provisions of this Section are not a limitation on the supplementary
authority granted by the Omnibus Bond Acts, and (iii) that instruments
issued under this Section within the supplementary authority granted
by the Omnibus Bond Acts are not invalid because of any provision of
this Act that may appear to be or to have been more restrictive than
those Acts.
This amendatory Act of 1971 is not a limit upon any municipality which
is a home rule unit.
This amendatory Act of 1972 is not a limit upon any municipality which
is a home rule unit.
(Source: P.A. 86-4.)
(65 ILCS 5/9-2-52) (from Ch. 24, par. 9-2-52)
Sec. 9-2-52.
Whenever sufficient funds are on hand, the corporate
authorities of the municipality issuing improvement bonds shall direct
the treasurer, or such other officer as may be designated by ordinance
for that purpose, to select by lot, bonds of series to be paid, or the
corporate authorities shall direct the treasurer or the other officer so
designated to make a pro rata payment on all unpaid bonds in the series.
The treasurer or other officer so designated shall send notice by
registered mail to the address of the known owner of each of the
designated bonds as set out in the treasurer's records, specifying a day
not less than 30 days after the date of the notice, upon which the
designated bonds will be paid either in full or in part, as the case may
be, at his office. He shall also supplement this notice by publishing a
notice of the number of bonds to be so paid, not less than 15 days prior
to the day set for payment, in one or more newspapers published in the
municipality, or, if no newspaper is published therein, then in one or
more newspapers with a general circulation within the municipality. In
municipalities with less than 500 population in which no newspaper is
published, publication may instead be made by posting a notice in 3
prominent places within the municipality, the series thereof, the
assessment to which they relate and the particular bonds so selected to
be paid if payment is to be made in full or in case a pro rata payment
is to be made, naming the particular series upon which the partial
payment is to be made, and that the same will be paid at a place to be
specified.
Thereupon from the specified date of payment these bonds shall be
payable on demand either in full or in part, as the case may be, at the
place so appointed. No further interest shall accrue on the bonds
selected to be paid in full or on that portion of the principal on bonds
to be paid in part. However, in municipalities, having a population of
100,000 or more, the selection by lot and the mailing and publishing of
notice may be omitted if bonds or vouchers in any series having
sufficient funds on hand are presented for payment. In this latter case
the bonds so presented may be paid in full, both as to principal and
interest, in their order of presentation, within the limits of the funds
available.
The provisions of this section shall apply to all proceedings now
pending, proceedings in which judgment has been entered, and all future
proceedings, except that the provisions of this section shall not apply
to bonds issued under Section 9-2-127.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-53) (from Ch. 24, par. 9-2-53)
Sec. 9-2-53.
Petitioner, in addition to other notices hereinbefore provided
for, shall publish a notice at least twice, not more than 30 nor less than
15 days in advance of the time at which confirmation of the specified
assessment is to be sought, in one or more newspapers published in the
municipality or, if no newspaper is published therein, then in one or more
newspapers with a general circulation within the municipality. In
municipalities with less than 500 population in which no newspaper is
published, publication may be made by posting a notice in 3 prominent
places within the municipality. The notice shall be over the name of the
officer levying the assessment, and shall be substantially as follows:
"Notice is hereby given to all persons interested that the city council
(or board of trustees, or other corporate authority, as the case may be) of
.... having ordered that (here insert a brief description of the nature of
the improvement), the ordinance for the improvement being on file in the
office of the .... clerk, having applied to the .... court of .... county
for an assessment of the costs of the improvement, according to benefits,
and an assessment therefor having been made and returned to that court, the
final hearing thereon will be had on (insert date), or as soon thereafter as the business of the court will permit. All
persons desiring may file objections in that court before that day and may
appear on the hearing and make their defense."
(Here give date.)
.....
Where the assessment is payable in installments, the number of
installments and the rate of interest also shall be stated.
(Source: P.A. 91-357, eff. 7-29-99.)
(65 ILCS 5/9-2-54) (from Ch. 24, par. 9-2-54)
Sec. 9-2-54.
If 15 days have not elapsed between the first publication or
the putting up of such notice, and the day fixed in the notice for filing
objections, the cause shall be continued for 15 days, and the time for
filing objections shall be correspondingly extended.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-55) (from Ch. 24, par. 9-2-55)
Sec. 9-2-55.
Any person interested in any real estate to be affected by an
assessment, may appear and file objections to the report, by the time
mentioned in the specified notice, or in case of incomplete notice then as
specified in the last preceding section, or within such further time as the
court may allow.
As to all lots, blocks, tracts, and parcels of land, to the assessment
of which objections are not filed within the specified time, or such other
time as may be ordered by the court, default may be entered, and the
assessment may be confirmed by the court, notwithstanding the fact that
objections may be pending and undisposed of as to other property.
(Source: P.A. 79-1361.)
(65 ILCS 5/9-2-56) (from Ch. 24, par. 9-2-56)
Sec. 9-2-56.
Upon objections or motion for that purpose, the court in which
the specified proceeding is pending may inquire in a summary way whether
the officer making the report has omitted any property benefited and
whether or not the assessment, as made and returned, is an equitable and
just distribution of the cost of the improvement, first, between the public
and the property, and second, among the parcels of property assessed. The
court has the power, on such application being made, to revise and correct
the assessments levied, to change or modify the distribution of the total
cost between the public and property benefited, to change the manner of
distribution among the parcels of private property, and to strike out of
the roll of awards by the commissioners filed in the case the amount or
amounts shown as compensation for property which property has been
theretofore donated by any person or persons for the making of the proposed
improvement, so as to produce a just and equitable assessment, considering
the nature of the property assessed, and its capacity for immediate use of
the improvement when completed.
The court may either make such corrections or changes, or determine in
general the manner in which the corrections or changes shall be made, and
refer the assessment roll to any competent person for revision, correction
or alteration in such manner as the court may determine. The determination
of the court as to the correctness of the distribution of the cost of the
improvement between the public and the property to be assessed, is
appealable as in other civil cases.
(Source: Laws 1967, p. 3762.)
(65 ILCS 5/9-2-57) (from Ch. 24, par. 9-2-57)
Sec. 9-2-57.
On the application of the petitioner, at any time after the
return day, the court may set down all objections, except the objection
that the property of the objector will not be benefited to the amount
assessed against it, and that it is assessed more than its proportionate
share of the cost of the improvement, for a hearing at a time to be fixed
by the court. Upon this hearing the court shall determine all questions
relating to the sufficiency of the proceedings, the distribution of the
cost of the improvement between the public and the property, and of the
benefits between the different parcels of property assessed, together with
all other questions arising in that proceeding, with the exception
specified, and shall thereupon enter an order in accordance with the
conclusions it reaches. But this order shall not be a final disposition of
any of those questions for the purpose of appeal, unless the objectors
waive further controversy as to the remaining question upon the record.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-58) (from Ch. 24, par. 9-2-58)
Sec. 9-2-58.
If it is objected on the part of any property assessed for
such an improvement, that it will not be benefited thereby to the amount
assessed thereon, and that it is assessed more than its proportionate share
of the cost of the improvement, and a jury is not waived by agreement of
parties, the court shall impanel a jury to try that issue. In that case,
unless otherwise ordered by the court, all such objections shall be tried
and disposed of before a single jury. The assessment roll, as returned by
the officer who made it, or as revised and corrected by the court on the
hearing of the legal objections, shall be prima facie evidence of the
correctness of the amount assessed against each objecting owner but shall
not be counted as the testimony of any witness or witnesses in the cause.
That assessment roll may be submitted to the jury and may be taken into the
jury room by the jury when it retires to deliberate on its verdict. Either
party may introduce such other evidence as may bear upon that issue or
issues. The hearing shall be conducted as in other civil cases. If it
appears that the property of any objector is assessed more than it will be
benefited by the specified improvement, or more than its proportionate
share of the cost of the improvement, the jury shall so find, and it shall
also find the amount for which that property ought to be assessed, and
judgment shall be rendered accordingly.
(Source: P.A. 79-1361.)
(65 ILCS 5/9-2-59) (from Ch. 24, par. 9-2-59)
Sec. 9-2-59.
Wherever, on a hearing by the court, or before a jury, the
amount of any assessment is reduced or cancelled, so that there is a
deficiency in the total amount remaining assessed in the proceeding, the
court may, in the same proceeding, distribute this deficiency upon the
other property in the district assessed, in such manner as the court finds
just and equitable, not exceeding, however, the amount such property will
be benefited by the specified improvement.
In case any portion of this deficiency is charged against such property
not represented in court, a new notice, of the same nature as the original
notice, shall be given in like manner as the original notice, to show the
cause why the assessment, as thus increased, should not be confirmed. The
owners of or parties interested in such property have the right to object
in the same form and with the same effect as in case of the original
assessment, and the court has the same power to dispose thereof.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-60) (from Ch. 24, par. 9-2-60)
Sec. 9-2-60.
The hearing in all the cases arising under this Division 2
shall have precedence over all other cases in any court, where they are
brought, except criminal cases, or other cases in which the public is a
moving party.
(Source: Laws 1967, p. 3740.)
(65 ILCS 5/9-2-61) (from Ch. 24, par. 9-2-61)
Sec. 9-2-61.
The court before which any such proceedings may be pending may
modify, alter, change, annul, or confirm any assessment returned as
specified, in addition to the authority already conferred upon it, and may
take all such proceedings, and make all such orders, as may be necessary to
the improvement, according to the principles of this article, and may from
time to time, as may be necessary, continue the application for that
purpose, as to the whole or any part of the premises.
After an ordinance for any local improvement has been filed in court,
and after the report and assessment roll relating thereto has been filed,
but before the court has entered its final judgment thereupon, the
corporate authorities may petition the court for the abandonment of any
portion of the proposed improvement. Such petition shall be supported by a
recommendation of the board of local improvements and an ordinance adopted
by the corporate authorities pursuant to Section 9-2-6 hereof, as amended
by this amendatory act of 1963. Upon the filing of such petition, the court
may order the adjustment of the assessment roll according to the changes
requested in the petition.
(Source: Laws 1963, p. 2424.)
(65 ILCS 5/9-2-62) (from Ch. 24, par. 9-2-62)
Sec. 9-2-62.
No special assessment or special tax shall be levied for any
local improvement until the land necessary therefor has been acquired and
is in possession of the municipality, except in cases where proceedings to
acquire such land have begun and have proceeded to judgment.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-63) (from Ch. 24, par. 9-2-63)
Sec. 9-2-63.
It is no objection to the legality of any local improvement
that a similar improvement has been previously made in the same locality,
if the ordinance therefor is recommended by the board of local
improvements, as above provided. But nothing contained in this Division 2
shall interfere with any defense in this proceeding relating to the
benefits received therefrom.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-64) (from Ch. 24, par. 9-2-64)
Sec. 9-2-64.
In case of a special assessment or a special tax levied to be
paid by installments, under the provisions of this Division 2, the order of
confirmation that is entered upon the return of the assessment roll shall
apply to all of the installments thereof, and may be entered in one order.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-65) (from Ch. 24, par. 9-2-65)
Sec. 9-2-65.
Judgment for special tax or assessment.
The judgments of
the court shall be final as to all the issues involved, and the proceedings
in the specified cause shall be subject to review by appeal as hereinafter
provided, and not otherwise. By mutual consent, however, a judgment may be
vacated or modified notwithstanding the expiration of 30 days from the
rendition of the judgment, except as hereinafter provided.
The judgment shall have the effect of several judgments as to each
tract or parcel of land assessed, and no appeal from any judgment
shall invalidate or delay the judgments, except as to the property
concerning which the appeal is taken.
The judgment shall be a lien on behalf of the municipality making an
improvement, for the payment of which the special tax or special assessment
is levied, on the property assessed from the date upon which a certified
copy of the judgment and assessment roll is recorded in the office of the
recorder of each county in which any part of the property is located, to
the same extent and of equal force and validity as a lien for the general
taxes until the judgment is paid or the property against which the judgment
is entered is sold to pay the judgment, if the judgment is recorded within
60 days from the date the assessment roll is confirmed. A judgment
recorded beyond the 60 days is not a valid lien against the property. This
60 day recording requirement does not
apply to judgments entered before September 23, 1991.
When the judgment against any property has been fully paid, the
corporate authorities of the municipality shall execute and record, in the
recorder's office of the county in which the land is located, a release of
the lien of the judgment so paid, and shall deliver a copy of the release
to the owner of the property.
Nothing in this Section shall interfere with the right of the petitioner
to dismiss its proceedings, and for that purpose to vacate a judgment
at its election at any time before commencing the actual collection of the
assessment. The court in which the judgment is rendered shall enter an
order vacating or annulling the judgment of confirmation on motion of
petitioner entered at any time after the expiration of 30 days from the
rendition of that judgment or confirmation upon a showing by petitioner
that no contract was let or entered into for the making of the specified
improvement within the time fixed by law for the letting of the contract,
that the making of the improvement under the original proceeding was
never commenced, or that the making of the improvement under the prior
proceedings was abandoned by petitioner. No judgment entered in a
proceeding so dismissed and vacated shall be a bar to another like or
different improvement. After the contract for the work has been
entered into, or the improvement bonds have been issued, however, no
judgment shall be vacated or modified or any petition dismissed after the
expiration of 30 days from the rendition of the judgment, and the
collection of the assessment shall not be in any way stayed or delayed by
the corporate authorities, board of local improvements, or any officer of
the municipality without the consent of the contractor and bondholder.
Subject to Sections 9-2-66 through 9-2-71, the
municipality or its assignee may file a complaint to foreclose the lien in
the same manner that foreclosures are permitted by law in case of
delinquent general taxes. No forfeiture of the property,
however, shall be required as a prerequisite to foreclosure.
(Source: P.A. 87-728; 87-895.)
(65 ILCS 5/9-2-66) (from Ch. 24, par. 9-2-66)
Sec. 9-2-66.
A municipality may file a petition in the circuit court praying
for the entry of an order authorizing the municipality to sell and assign
special assessment liens. Any number of properties and special assessment
liens may be included in a petition. Notice of the filing of the petition
and notice of the time and place of hearing on the petition shall be given
by the municipality to "Owners of the lots or tracts of land on which such
special assessments are liens" and to "Owners and holders of special
assessment bonds and vouchers" by publication in conformity with the
provisions of "An Act to Revise the Law in Relation to Notices", approved
February 13, 1874, as heretofore and hereafter amended. The municipality
shall also, within 10 days of the first publication of the notice, send a
copy thereof by mail addressed to each known owner and holder of special
assessment bonds and vouchers whose addresses are shown on the books and
records of the municipality. The municipality shall also, within 10 days of
the first publication of the notice, send a copy thereof by mail addressed
to each owner of lots or tracts of land on which the special assessment is
a lien and to a representative number of owners of lots or tracts of land
on which the special assessments have been paid, whose names and addresses
appear in the owner's column on the county collector's warrant for general
taxes for the year preceding the filing of the petition. A certificate of
the collector of special assessments of the municipality that he has sent
copies in pursuance of this section is evidence that he has done so. Except
as otherwise provided in this section and Sections 9-2-67 through 9-2-71,
the practice and procedure shall be the same as in other civil cases.
(Source: P.A. 79-1361.)
(65 ILCS 5/9-2-67) (from Ch. 24, par. 9-2-67)
Sec. 9-2-67.
The petition to sell and assign special assessment liens shall
allege that the special assessments are past due and unpaid, the total
amounts owing on each lot or tract of land, and that it is in the best
interest of the municipality and the owners of the special assessment bonds
and vouchers that the municipality be authorized to sell and assign the
special assessment liens.
The court shall hear the proceeding in a summary manner and there shall
be no hearing on benefits or on any legal objections arising prior to the
order or orders of confirmation of the special assessments. The Court on
such petition may enter an order authorizing the sale and assignment of all
or a part of the special assessment liens set forth in the petition. The
court in such order shall determine and find the amount of the special
assessment liens on each lot or tract of land on which it authorizes the
liens to be sold.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-68) (from Ch. 24, par. 9-2-68)
Sec. 9-2-68.
Pursuant to authorization by order of court, the municipality
may at public sale, after first giving notice by publication of the time
and place of sale in conformity with the provisions of "An Act to Revise
the Law in Relation to Notices", approved February 13, 1874, as heretofore
and hereafter amended, sell the special assessment lien or liens.
The special assessment liens shall be sold in the manner in which they
are assessed. The municipality shall file a report of sale in the circuit
court within 30 days of the date of sale of the lien on each tract or lot
and pray for an order of court confirming the sale. Upon confirmation, the
collector of special assessments of the municipality shall issue to the
purchaser a certificate of sale and assignment by the municipality of the
lien. Such certificate shall be countersigned by the county clerk. Each
certificate of sale shall state the amount of the sale and the amount of
the lien as determined by the court. Appropriate notations of the sale and
assignment of special assessment liens shall be made on the public records
of the municipality and the county by the official custodians thereof.
The county clerk shall prepare and keep a record in his office which
shall be known as the "special assessment sale, assignment and redemption
record", in which shall be entered all sales and assignments of special
assessment liens, the amount of the liens as determined by order of court,
payments made by the owners of lots or tracts of land to the county clerk
under the provisions of this Division 2 and redemptions. No sale and
assignment or cancellation of the special assessment lien or redemption
shall be valid unless and until the sale and assignment, cancellation or
redemption is entered on the records of the county clerk. The county clerk
shall be entitled to a fee of $1 for each lot or tract of land for entering
a sale and assignment on his record, which fee shall be included as costs
in case of redemption or foreclosure.
(Source: P.A. 79-1361.)
(65 ILCS 5/9-2-69) (from Ch. 24, par. 9-2-69)
Sec. 9-2-69.
Redemption of special assessment liens may be made prior to
the entry of a foreclosure judgment by payment to the county clerk of the
amount of the lien as determined by order of court, together with interest
thereon at the rate of 12% for each 6 months or portion thereof intervening
between the time of sale and the time of redemption. Redemptions made after
foreclosure judgment and sale shall be the same as provided for in Section
21-75 of the Property Tax Code.
The county clerk shall be entitled to the same fees for issuing
estimates of the cost of redemption, issuing certificates of cancellation,
certificates of redemption and cancelling sales of special assessment liens
as he is presently entitled to by law in regard to tax sales.
(Source: P.A. 88-670, eff. 12-2-94.)
(65 ILCS 5/9-2-70) (from Ch. 24, par. 9-2-70)
Sec. 9-2-70.
The assignee of a special assessment lien may, not later than
5 years after the date of the sale and assignment of the special assessment
lien by the municipality, file a complaint to foreclose the lien. The lien
of a special assessment which has been assigned and any right of action to
foreclose the same shall not expire during the pendency of a proceeding to
foreclose the lien commenced within 5 years from the date of the sale and
assignment of the lien by the municipality. If no action is commenced
within 5 years from the date the lien is assigned by the municipality, the
lien and all right of action to enforce the same shall expire and cease to
exist.
The assignee of a special assessment lien sold or assigned on or
prior to December 31, 1957 may, not later than 5 years after the
effective date of this amendatory Act of 1975, file a complaint to
foreclose the lien. The lien of a special assessment which has
been assigned and any right of action to foreclose the same shall not
expire during the pendency of a proceeding to foreclose the lien
commenced within 5 years after the effective date of this amendatory
Act of 1975. If no action is commenced within 5 years, the lien and
all right of action to enforce the same shall expire and cease to
exist.
(Source: P.A. 79-198.)
(65 ILCS 5/9-2-71) (from Ch. 24, par. 9-2-71)
Sec. 9-2-71.
The cost and expense attending the sale and assignment of a
special assessment lien by a municipality, not exceeding 10% of the amount
of the lien, shall be assessed as costs and shall be paid by the assignee.
However, no lien created after September 1, 1949 shall be sold or assigned
by a municipality as long as any obligation of any kind secured by such
lien remains outstanding and unpaid.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-72) (from Ch. 24, par. 9-2-72)
Sec. 9-2-72.
If any special assessment or special tax before January 1,
1942 has been, or on or after January 1, 1942, is annulled by the corporate
authorities, or set aside by any court or declared invalid or void for any
reason whatsoever, a new assessment or tax may be made and returned and
like notice shall be given and proceedings had as required in this Division
2 in relation to the first. If any local improvement before January 1, 1942
has been, or on or after January 1, 1942, is constructed under the
direction of the board of local improvements and has been or is accepted by
that board, and the special assessment or special tax levied or attempted
to be levied to pay for the cost of such an improvement has been or is so
annulled, set aside, or declared invalid or void, then a new special
assessment or special tax may be made and returned to pay for the cost of
the improvement so constructed, or to pay for the cost of such part thereof
as the corporate authorities might lawfully have authorized to be
constructed and paid for by special assessment or special tax. All parties
in interest shall have like rights, and the corporate authorities and the
court shall perform like duties and have like power in relation to any
subsequent assessment or tax as are provided in relation to the first.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-73) (from Ch. 24, par. 9-2-73)
Sec. 9-2-73.
No special assessment or special tax shall be held invalid
because levied for work already done, if it appears that the work was done
under a contract which has been duly let and entered into pursuant to an
ordinance providing that such an improvement should be constructed and paid
for by special assessment or special tax, and that the work was done under
the direction of the board of local improvements and has been accepted by
that board. It shall not be a valid objection to the confirmation of this
new assessment that the original ordinance has been declared invalid or
that the improvement as actually constructed does not conform to the
description thereof as set forth in the original special assessment
ordinance, if the improvement so constructed is accepted by the board of
local improvements. The provisions of this section shall apply whenever the
prior ordinance is held insufficient or otherwise defective, invalid, or
void, so that the collection of the special assessment or special tax
therein provided for becomes impossible. In every such case, when such an
improvement has been so constructed and accepted, and the proceedings for
the confirmation and collection of the special assessment or special tax
are thus rendered unavailing, the corporate authorities shall pass a new
ordinance for the making and collection of a new special assessment or
special tax, and this new ordinance need not be presented by the board of
local improvements.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-74) (from Ch. 24, par. 9-2-74)
Sec. 9-2-74.
At any time after the bids have been received pursuant to the
provisions of this Division 2, if it appears to the satisfaction of the
board of local improvements that the first assessment is insufficient to
pay the contract price or the bonds or vouchers issued or to be issued in
payment of the contract price, together with the amount required to pay the
accruing interest thereon, the board shall make and file an estimate of the
amount of the deficiency. Thereupon a second or supplemental assessment for
the estimated deficiency of the cost of the work and interest may be made
in the same manner as nearly as may be as in the first assessment, and so
on until sufficient money has been realized to pay for the improvement and
the interest. It shall be on objection to the supplemental assessment that
the prior assessment has been levied, adjudicated, and collected unless it
appears that in that prior cause upon proper issue made, it was specially
found in terms, that the property objected for would be benefited by the
improvement no more than the amount assessed against it in that prior
proceedings.
If too large a sum is raised at any time, the excess shall be refunded
ratably to those against whom the assessment was made.
But if the estimated deficiency exceeds 10% of the original estimate, no
contract shall be awarded until a public hearing has been held on the
supplemental proceeding in like manner as in the original proceedings. No
more than one supplemental assessment shall be levied to meet any
deficiency where the deficiency is caused by the original estimate made by
the engineer being insufficient.
Where the improvement is to be constructed with the aid and assistance
of any federal agency or other governmental agency after judgment of
confirmation if there appears a deficiency in assessments levied in excess
of 10% of the original estimate the municipality shall not proceed with the
construction of the work until a new hearing has been held upon the levy of
a special assessment to make up that deficiency.
However, the petitioner, in case it so elects, may dismiss the petition
and vacate the judgment of confirmation at any time after the judgment of
confirmation is rendered, and begin new proceedings for the same or a
different improvement as provided in Section 9-2-65.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-75) (from Ch. 24, par. 9-2-75)
Sec. 9-2-75.
If from any cause any municipality fails to collect the whole
or any portion of any special assessment or special tax which may be
levied, which is not canceled or set aside by the order of any court, for
any public improvement authorized to be made and paid for by a special
assessment or a special tax, the corporate authorities, at any time within
5 years after the confirmation of the original assessment, may direct a new
assessment to be made upon the delinquent property for the amount of the
deficiency and interest thereon from the date of the original assessment,
which assessment shall be made, as nearly as may be, in the same manner as
is prescribed in this Division 2 for the first assessment. In all cases
where partial payments have been made on such former assessments, they
shall be credited or allowed on the new assessment to the property for
which they were made, so that the assessment shall be equal and impartial
in its results. If this new assessment proves insufficient, either in whole
or in part, the corporate authorities, at any time within the specified
period of 5 years, may order a third to be levied, and so on in the same
manner and for the same purpose. It shall constitute no legal objection to
any new assessment that the property may have changed hands, or been
encumbered subsequent to the date of the original assessment.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-76) (from Ch. 24, par. 9-2-76)
Sec. 9-2-76.
Within 30 days after the filing of the report of the amount
and date of the first voucher issued on account of work done, as provided
in Section 9-2-48, the clerk of the court in which such judgment is
rendered shall certify the assessment roll and judgment to the officer of
the municipality authorized to collect the special assessment, or, if there
has been an appeal taken on any part of the judgment, he shall certify such
part of the judgment as is not included in that appeal. This certification
shall be filed by the officer receiving it in his office. With the
assessment roll and judgment the clerk of the designated court shall also
issue a warrant for the collection of the assessment. The court has the
power to recall such warrants as to all or any of the property affected at
any time before payment or sale, in case the proceedings are abandoned by
the petitioner or the judgment is vacated or modified in a material respect
as hereinbefore provided, but not otherwise. In case the assessment roll
has been abated and the judgment reduced in accordance with the provisions
of Section 9-2-114, the clerk of the designated court, within 30 days
thereafter, shall certify the order of reduction or the roll as so reduced
or re-cast, under the directions of the court, to the officer so authorized
to collect the special assessment, and shall issue a warrant for the
collection of the assessment as so reduced or re-cast.
(Source: P.A. 76-1556.)
(65 ILCS 5/9-2-77) (from Ch. 24, par. 9-2-77)
Sec. 9-2-77.
Whenever any warrant is issued by the clerk of the court in
which the judgment of confirmation is rendered, for the collection of any
special assessment specified in Section 9-2-19, that warrant shall not
authorize the collection of any assessment levied against the municipality
for and on account of public benefits, but the clerk shall likewise certify
the assessment roll and judgment to the clerk or comptroller, if any, of
that municipality upon being requested so to do by that officer. The
several and respective installments of the amounts that may be assessed
against the municipality for and on account of public benefits and
confirmed by the court, shall be paid out by the municipal treasurer out of
any money arising from the collection of the direct annual tax provided for
in Section 9-2-38 and out of any other money in his hands that may be used
for that purpose whenever he is legally authorized so to do, by an
ordinance of that municipality. Any such municipality may pay for any land
to be taken or damaged in the making of any local improvement specified in
Section 9-2-19, before any such assessment or any installment thereof
becomes due, and when the same becomes due, the amount so paid shall be
credited upon the assessment against the municipality so paying in advance.
The provisions of this section shall not apply to any city having a
population of 500,000 or more.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-78) (from Ch. 24, par. 9-2-78)
Sec. 9-2-78.
If an appeal is taken on any part of such judgment, and if the
board elects to proceed with the improvement, notwithstanding
such an appeal, as provided for in Section 9-2-102, the clerk shall certify the
appealed portion, from time to time, in the manner above mentioned, as the
judgment is rendered thereon, and the warrant accompanying this certificate
in each case shall be authority for the collection of so much of the
assessment as is included in the portion of the roll thereto attached.
The warrant in all cases of assessment, under this Division 2, shall
contain a copy of the certificate of the judgment describing lots, blocks,
tracts, and parcels of land assessed so far as they are contained in the
portion of the roll so certified, and shall state the respective amounts
assessed on each lot, block, tract, or parcel of land, and shall be
delivered to the officer authorized to collect the special assessment. The
collector having a warrant for any assessment levied to be paid by
installments may receive any or all of the installments of that assessment,
but if he receives only a part of the installments, then he shall receive
them in their numerical order.
(Source: P.A. 90-655, eff. 7-30-98.)
(65 ILCS 5/9-2-79) (from Ch. 24, par. 9-2-79)
Sec. 9-2-79.
The collector receiving such a warrant shall give notice
thereof within 10 days by publishing a notice once each week for 2
successive weeks in one or more newspapers published in the municipality,
or, if no newspaper is published therein, then in one or more newspapers
with a general circulation within the municipality. In municipalities with
less than 500 population in which no newspaper is published, publication
may instead be made by posting a notice in 3 prominent places within the
municipality. This notice may be substantially in the following form:
Dated (insert date).
When such an assessment or special tax is levied to be paid in
installments, the notice shall contain also the amount of each installment,
the rate of interest deferred installments bear, and the date when payable.
(Source: P.A. 91-357, eff. 7-29-99.)
(65 ILCS 5/9-2-80) (from Ch. 24, par. 9-2-80)
Sec. 9-2-80.
The collector, into whose possession the warrant comes, as
far as practicable, shall call upon all persons, resident within the
neighborhood, whose names appear upon the assessment roll, or the occupants
of the property assessed, and personally, or by written or printed notices
left at his or her usual place of abode or mailed to all persons whose
names appear on the assessment roll, inform them of the special assessment,
and request payment thereof. This notice shall be given by the collector
within 10 days after his receipt of the warrant and shall indicate the
date on or before which the assessment may be paid in whole or in part
without interest. Under Section 9-2-48 interest on assessments shall begin
to run from 60 days after the date of the first voucher issued on account
of work done, except as otherwise provided in Section 9-2-113.
Any collector omitting to do so is liable to a penalty of $10 for every
such omission, but the validity of the special assessment, or the right to
apply for and obtain judgment thereon, is not affected by such an omission.
It is the duty of such collector to write the word "paid" opposite each
tract or lot on which the assessment is paid, together with the name and
post office address of the person making the payment, and the date of
payment.
(Source: P.A. 87-532.)
(65 ILCS 5/9-2-81) (from Ch. 24, par. 9-2-81)
Sec. 9-2-81.
In cities of this state having a population of 1,000,000
or more, when any officer is authorized to collect special assessments
or special taxes, that officer, on or before March 10 each year, or if the
general tax books have not been turned over to the county collector at that
time then within 15 days after the county collector has received the
general tax books, shall mark on the general tax books of the county
collector, opposite the description of all lots, blocks, tracts, or parcels
of land to be assessed, the number of the special assessment or special tax
warrant. The county collector shall stamp or write in large letters on the
face of all tax bills or receipts issued by him the number of the special
assessment or special tax warrant, and the words, "Special assessment due
and payable."
(Source: P.A. 82-1013.)
(65 ILCS 5/9-2-82) (from Ch. 24, par. 9-2-82)
Sec. 9-2-82.
In counties having a population of 1,000,000
or more the collector shall, on or before the first day of August in each
year, make a report in writing to the general officer of the county (in which the
respective lots, tracts, and parcels of land are situated) authorized by
the general revenue laws of this State to apply for judgment and sell land
for taxes due the county and State, of all the land, town lots, and real
property on which he has been unable to collect special assessments or
special taxes, or installments thereof matured and payable, or interest
thereon, or interest due to the preceding January 2 on installments not yet
matured on all warrants in his possession, with the amount of those
delinquent special assessments or special taxes or installments and
interest together with his warrants; or, in case of an assessment levied to
be paid by installments, with a brief description of the nature of the
warrant or warrants received by him authorizing the collection thereof.
This report shall be accompanied with the oath of the collector (1) that
the list is a correct return and report of the land, town lots, and real
property on which the special assessment or special tax (levied by the
authority of the city or incorporated town or village of .... as the case
may be), or installments thereof, or interest, remains due and unpaid, (2)
that he is unable to collect the same, or any part thereof, and (3) that he
has given the notice required by law that the specified warrants have been
received by him for collection.
(Source: P.A. 82-1013.)
(65 ILCS 5/9-2-83) (from Ch. 24, par. 9-2-83)
Sec. 9-2-83.
In counties having a population of less than 1,000,000,
the general officer of the county having authority to receive State and
county taxes shall, not later than August 15 each year, designate a day in
the month of October upon which application will be made for judgment and
order of sale for unpaid special assessments or installments thereof, and
interest thereon, on delinquent land, town lots, and real property and also
a Monday succeeding the date of that application, on which the land and
lots for the sale of which an order is made will be exposed to public sale,
and shall forthwith notify the collectors of all municipalities situated in
whole or in part within the county of the dates so designated.
(Source: P.A. 85-1137.)
(65 ILCS 5/9-2-84) (from Ch. 24, par. 9-2-84)
Sec. 9-2-84.
In counties having a population of less than 1,000,000,
the collector of the municipality, at any time after August 15 in each
year, shall publish an advertisement that a return will be made to the general
officer of the county having authority to receive State and county taxes of
all unpaid special assessments or installments thereof matured and payable,
or interest thereon, or interest due to the preceding January 2 on
installments not yet matured on all warrants in his hands. This
advertisement (1) shall contain a list of the delinquent lands, town lots,
and real property upon which the special assessment or installments thereof
or interest thereon remain unpaid, the name of the
person shown by the county collector's current warrant book
to be the party in whose name the general real estate taxes were last
assessed for each such property, the
total amount due thereon, and the year for which the same are due; (2)
shall give notice that the general officer of the county having authority
to receive State and county taxes in the county in which those lands, town
lots, or real property may be located, will make application on the day
specified therein, for judgment against those lands, town lots, and real
property for those special assessments, matured installments of special
assessments, interest and costs due thereon, and for an order to sell those
lands, town lots, and real property for the satisfaction thereof; and (3)
shall give notice that on the Monday fixed by that general officer of the
county for sale, all the lands, town lots, and real property, for the sale
of which an order is made, will be exposed to public sale at the court
house in that county for the amount of special assessments and matured
installments of special assessments, interest and costs due thereon. The
advertisement shall be sufficient notice of the intended application for
judgment and of the sale of those lands, town lots, and real property under
the order of the court.
Publication of the advertisement shall be made at least once not more
than 30 nor less than 15 days in advance of the date upon which the
judgment is to be sought. Such publication shall be made in one or more
newspapers published in the municipality, or if no newspaper is published
therein then in one or more newspapers with a general circulation in the
municipality. In municipalities with less than 500 inhabitants, publication
may instead be made by posting a notice in 3 prominent places within the
municipality.
The municipal collector shall add to all special assessments and matured
installments of special assessments and the interest thereon, when paid
after August 15 in the year when they became due and payable, an amount
equal
to the actual costs,
not to exceed 0.2% of the assessed value of each lot, tract, or parcel of land
upon which payment is made, to
cover the cost of the advertisement as required in this Division 2.
(Source: P.A. 91-864, eff. 6-22-00.)
(65 ILCS 5/9-2-85) (from Ch. 24, par. 9-2-85)
Sec. 9-2-85.
In counties having a population of less than 1,000,000,
the collector of the municipality, not later than 5 days prior
to the date fixed for application for judgment, shall make a return or report in
duplicate upon forms to be provided by the county collector to the general
officer of the county having authority to receive State and county taxes in
the county in which the respective lots, tracts, and parcels of land are
situated. Such report shall list all the land, town lots, and real property
on which he has been unable to collect the special assessments or special
taxes or installments, thereof, matured and payable or interest thereon, or
interest due to the preceding January 2 on installments not yet matured on
all warrants in his possession. Also contained in the report shall be a
list of the amount of those delinquent special assessments or special taxes
or installments and interest together with a brief description of the
warrant or warrants received by him, authorizing the collection thereof.
The original of this report shall be accompanied with the oath of the
collector (1) that the list is a correct return and report of the land,
town lots, and real property on which the special assessment or special tax
(levied by the authority of the city or incorporated town or village of
...., as the case may be), or installments thereof, or interest, remains
due and unpaid, (2) that he is unable to collect the same, or any part
thereof, (3) that he has given the notice required by law that the
specified warrants have been received by him for collection, and (4) that
he has published an advertisement in the manner prescribed by law, giving
notice that an application will be made on the date specified therefor for
judgment against all of those delinquent lands, town lots, and real
property.
(Source: P.A. 82-1013.)
(65 ILCS 5/9-2-86) (from Ch. 24, par. 9-2-86)
Sec. 9-2-86.
The report of the municipal collector, when so made, shall be
prima facie evidence that all the forms and requirements of the law, in
relation to the making of the return have been complied with, and that the
special assessments, or special taxes, or the matured installments thereof,
and the interest thereon, and the interest accrued on installments not yet
matured, mentioned in the report, are due and unpaid.
Upon the application for judgment of sale upon such an assessment or
matured installments thereof, or the interest thereon, or the interest
accrued on installments not yet matured, no defense or objection shall be
made or heard which might have been interposed in the proceeding for the
making of that assessment, or the application for the confirmation thereof.
No errors in the proceeding to confirm not affecting the power of the court
to entertain and consider the petition therefor, shall be deemed a defense
to the application provided for in this Division 2.
When such an application is made for judgment of sale on an installment
only of an assessment payable by installments, all questions affecting the
jurisdiction of the court to enter the judgment of confirmation and the
validity of the proceedings shall be raised and determined on the first of
such applications. On application for judgment of sale on any subsequent
installment, no defense, except as to the legality of the pending
proceeding, the amount to be paid, or actual payment, shall be made or
heard. And it shall be no defense to the application for judgment on any
assessment or any installment thereof that the work done under any
ordinance for an improvement does not conform to the requirements of that
ordinance, if it appears that the work has been accepted by or under the
direction of the board of local improvements. And the voluntary payment by
the owner or his agent, of any installment, or of any assessment, levied on
any lot, block, tract, or parcel of land, shall be held in law to be an
assent to the confirmation of the assessment roll, and shall be held to
release and waive the right of the owner to enter objections to the
application for judgment of sale and order for sale.
The judgment of sale on any installment shall include all interest
accrued on the installment up to the date of that judgment of sale, and
also the annual interest due as returned delinquent by the municipal
collector on any installment or installments not matured. All judgments of
sale for a matured installment shall bear interest on the amount of the
principal of that matured installment to the date of payment or sale.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-87) (from Ch. 24, par. 9-2-87)
Sec. 9-2-87.
When the specified general officer in each county receives the
report provided for, he shall proceed to obtain judgment against the lots
and parcels of land and property for the special assessments and the
special taxes, or installments thereof, and interest remaining due and
unpaid, in the same manner as is or may be by law provided for obtaining
judgment against lands for taxes due and unpaid the county or State except
that in counties having a population of less than 1,000,000,
no other notice of the application for this judgment shall be required than
that specified in this Division 2 to be given by the collector of the municipality.
The general collecting officer of the county shall proceed in the same manner
to sell the same for the specified special assessments, special taxes, or
installments thereof, and interest remaining due and unpaid except that in
counties having a population of less than 1,000,000, no
other notice of sale shall be required than that specified in this Division
2 to be given by the
collector of the municipality. In obtaining these judgments and making this
sale, the general collecting officer of the county shall be governed by the
general revenue law of the State except as otherwise provided in this
Division 2.
No application for judgment against land for unpaid special taxes or
special assessments shall be made at a time different from the annual
application for judgment against land upon which general taxes remain due
and unpaid.
The application for judgment upon delinquent special assessments or
special taxes in each year shall include only such special assessments,
special taxes, or installments thereof, and interest, as have been returned
as delinquent to the county collector on or before the first day of August
in the year in which the application is made, and marked on the general tax
books of the county collector on or before March 10, as provided in Section
9-2-81. However, in counties having a population of less than 1,000,000, such
application shall include only the special assessments, special taxes, or
installments thereof, and interest as have been returned or reported as
delinquent to the general collecting officer of the county not less than 5
days prior to the date designated for application for judgment, in the year
in which the application is made. Such judgment of sale shall include
interest on matured installments up to the date of the judgment, as
provided in this Division 2.
In the 5 years next following the completion of a general reassessment
of real property in any county having a population of 1,000,000
or more, made pursuant to an order of the Department of Revenue of the State
of Illinois,
notwithstanding that those special assessments, special taxes, or
installments thereof, and interest, have not been returned as delinquent to
the county collector on or before the first day of August in the year in
which the application is made, and notwithstanding that those special
assessments, special taxes, or installments thereof, and interest, were not
marked on the general tax books of the county collector on or before March
10 of the same year as provided in Section 9-2-81 or within 15 days after
the county collector received the general tax books in that year, such an
application shall be made on the first day of September for judgment and
order of sale for special assessments, special taxes, or installments
thereof, and interest, in each year on delinquent lands and lots. The
county collector shall include in that application all special assessments,
special taxes, and installments thereof, and interest, then remaining
unpaid. Within 30 days after the county collector has received the general
tax books the special assessments, special taxes, or installments thereof,
and interest, then remaining unpaid, shall be marked therein, and if for
any reason, that application cannot be made on the first day of September,
it shall be made at any time not later than the first day of the next
succeeding January.
In counties having a population of less than 1,000,000,
the application for judgment and order of sale, and the sale, shall be made on the
respective days previously designated by the general collecting officer of
the county.
(Source: P.A. 82-1013.)
(65 ILCS 5/9-2-88) (from Ch. 24, par. 9-2-88)
Sec. 9-2-88.
In counties having a population of less than 1,000,000
in all cases, except where land or lots have been withdrawn from collection for
want of bidders or forfeited to the State for nonpayment of special
assessments 2 or more years in succession next preceding the year in which
the application for judgment and order of sale is made, the collector of
the municipality shall send a notice of the application for judgment and
sale of the land or lots upon which special assessments remain due and
unpaid, the date of sale, a description of the land or lots, and the amount
of the special assessments together with interest and costs due thereon.
The notice shall be sent by mail, either by letter or post card, postage
prepaid, at least 5 days before the date of sale. The notice shall be addressed
to the person shown by the county collector's current warrant book to be the
party in whose name the general real estate taxes on such property were
last assessed, and such notices shall be mailed to each such party at the
address shown for such party in the county collector's current warrant
book. For each such notice the collector of the municipality shall charge
an amount equal to the actual costs, not to exceed 0.02% of the assessed
value of each parcel, to be taxed and collected as costs.
(Source: P.A. 91-864, eff. 6-22-00.)
(65 ILCS 5/9-2-89) (from Ch. 24, par. 9-2-89)
Sec. 9-2-89.
In counties having a population of less than 1,000,000,
any person owning or claiming land or lots upon which judgment
is prayed, as
provided in this Division 2, may pay the special taxes, special
assessments, interest, and costs due thereon to the collector of the
municipality in which the land or lots are situated at any time before
sale. On the day fixed for sale, the collector shall report, under oath, to
the county clerk, all the land or lots upon which special assessments have
been paid, if any, after the time of making the return mentioned in Section
9-2-85 and prior to that day. The clerk shall note this fact opposite each
tract or lot upon which those payments have been made. This report shall
include a statement by the collector, under oath, that notice of sale has
been sent by mail, by letter or post card, as to all other land or lots
included in the report as required by Section 9-2-88.
(Source: P.A. 82-1013.)
(65 ILCS 5/9-2-90) (from Ch. 24, par. 9-2-90)
Sec. 9-2-90.
After making the specified sale, the list of lots, parcels of
land, and property sold thereat shall be returned to the office of the
county clerk and redemption may be made as provided for by the general
revenue laws of the State.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-91) (from Ch. 24, par. 9-2-91)
Sec. 9-2-91.
In counties having a population of less than 1,000,000,
a list of all lots, parcels of land, and property withdrawn
from collection at the sale by the corporate authorities levying the tax
and a list of all lots,
parcels of land, and property charged with delinquent special assessments
which were forfeited to the State at that sale, shall be returned by the
county clerk to the office of the municipal collector, where payment of any
delinquent special assessment so withdrawn from collection or forfeited to
the State may be made, as in the case of redemption from sale, at any time
thereafter, unless and until again advertised and offered for sale and sold
for the non-payment thereof.
(Source: P.A. 82-1013.)
(65 ILCS 5/9-2-92) (from Ch. 24, par. 9-2-92)
Sec. 9-2-92.
In counties having a population of 1,000,000
or more, a list of
all lots, parcels of land, and property withdrawn from collection at that
sale by the corporate authorities levying the tax and a list of all lots,
parcels of land, and property charged with delinquent special assessments
which were forfeited to the State at that sale, shall also be returned to
the office of the county clerk where payment of any delinquent special
assessment so withdrawn from collection or forfeited to the State may be
made, as in the case of redemption from sale at any time while the same is
withdrawn from the county collector, or forfeited, or thereafter, if again
advertised and sold, until the period of redemption at such subsequent sale
under the general revenue laws of the State has expired and a tax deed is
issued thereon.
(Source: P.A. 82-1013.)
(65 ILCS 5/9-2-93) (from Ch. 24, par. 9-2-93)
Sec. 9-2-93.
In case of such a payment of a withdrawn or forfeited special
assessment, the municipal collector or county clerk, as the case may be,
shall collect a penalty of 12% on the amount of the forfeiture and on the
amount of the withdrawn special assessment together with interest and costs
to the date of withdrawal or forfeiture for the first year after the date
of that withdrawal or forfeiture, and after that first year interest at the
rate of 6% annually. The municipal collector or the county clerk, as the
case may be, shall pay over to the officer of the municipality entitled to
receive the same, within 30 days after the collection has been made, all
special assessments, together with interest, penalties, and also statutory
costs advanced by the municipality and collected by him. But if any lot or
parcel of land should again be offered for sale, because of failure to pay
that delinquent special assessment, and again withdrawn from sale, there
shall be no second charge of 12% for the first year following the
subsequent withdrawal. Instead, the interest rate shall continue at the
rate of 6% annually. There may be second and subsequent charges of 12%
for successive forfeitures.
The municipal collector or county clerk shall be entitled to charge and
collect from the person for whom the service is rendered, a fee of 40 cents
for each estimate of the amount necessary to pay a withdrawn or forfeited
special assessment, including costs, and a fee of $1 for each certificate
of deposit for payment of such a withdrawn or forfeited special assessment.
(Source: P.A. 85-1137.)
(65 ILCS 5/9-2-94) (from Ch. 24, par. 9-2-94)
Sec. 9-2-94.
In counties having a population of 500,000 or more, the city
comptroller or other officer designated and authorized by the corporate
authorities of any municipality which levies any special assessment has the
power to collect the amounts due on tracts or lots which have been
forfeited or withdrawn from sale, and the interest and penalties due
thereon, based upon an estimate of the cost of redemption computed by the
county clerk and at a rate to be fixed by the corporate authorities as to
the interest and penalties thereon, and he shall issue a receipt therefor.
However, the corporate authorities may authorize the municipal officer to
waive the penalties for the first year in excess of 7%. The person
receiving this receipt shall file it with the county clerk.
Upon the presentation of such a receipt, the county clerk shall issue to
the person a certificate of cancellation setting forth a description of the
property, the special assessment warrant, and installment, and the amount
received by the municipal officer, and this certificate of cancellation
shall be evidence of the redemption of the property therein described. The
form of such a certificate of redemption for filing with the county clerk
shall be substantially as follows: Receipt of Deposit for Redemption.
I, (here give name, title of municipal officer), of the (give name of
city, village, or incorporated town), do hereby certify that on (insert
date), .... deposited in this office ....
Dollars for the redemption of .... (describe property) .... which ....
withdrawn or forfeited by the collector of this county on (insert date) for the
nonpayment of .... installment of special
assessment warrant.
You are hereby authorized and ordered to cancel from the records and
files in your office that withdrawal or forfeiture, and issue your
certificate of redemption and cancellation.
(insert date).
(insert name of city, village, or incorporated town).
(65 ILCS 5/9-2-95) (from Ch. 24, par. 9-2-95)
Sec. 9-2-95.
If the collector receives any money for taxes or assessments,
or installments thereof, and gives a receipt therefor, for any land or
parcel of land, and afterwards makes a return that the tax assessment, or
installment thereof was unpaid, to the State officers authorized to sell
land for taxes, or receives the amount so payable after that return has
been made, and that property is sold for any tax, assessment, or
installment thereof which has been so paid and receipted for by himself or
his clerks, the collector and his bondsmen shall be liable to the holder of
the certificate given to the purchaser at that sale for double the amount
of the face of the certificate. This sum may be demanded in 2 years from
the date of the sale, and recovered in any court having jurisdiction of the
amount. The municipality in no case shall be liable to the holder of such a
certificate.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-96) (from Ch. 24, par. 9-2-96)
Sec. 9-2-96.
The collector and the general officer to whom the warrants are
returned, shall pay over to the municipal treasury to which the money
belongs, all money collected by them, respectively, by virtue of such
warrants, or upon any sale for taxes, or otherwise, at such time or times
and in such manner as shall be prescribed by ordinance. They shall be
allowed such compensation for their services in the collection of these
assessments as the ordinance of the municipality may provide, except when
their compensation is fixed by a general law.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-97) (from Ch. 24, par. 9-2-97)
Sec. 9-2-97.
The general revenue laws of this State, with reference to proceedings to
recover judgment for delinquent taxes, the sale of property thereon, the
execution of certificates of sale and deeds thereon, the force and effect
of such sales and deeds, and all other laws in relation to the enforcement
and collection of taxes, and redemption from tax sales, except as otherwise
provided in this Division 2, shall be applicable to proceedings to collect
the special assessments and special taxes provided for in this Division 2.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-98) (from Ch. 24, par. 9-2-98)
Sec. 9-2-98.
Except as otherwise provided in Section 9-2-113, any
municipality interested in the collection of any tax or special assessment,
in default of other bidders, may become a purchaser at any sale of property
to enforce the collection of that tax or special assessment, and by
ordinance may authorize and make it the duty of one or more municipal
officers to attend such sales and bid thereat in behalf of the
municipality. Such a municipality, through its officer or officers, acting
under like authority, in default of bidders, may withdraw from collection
at such a sale any special assessment or installment thereof levied by it
on any lot, parcel of land, or property subject to sale. But such a
withdrawal from collection shall not operate to cancel the assessment or
impair the lien of the municipality so withdrawing it, and the assessment
shall remain delinquent and payable at the office of the municipal
collector or county clerk, with all fees, costs, penalties, interest, and
charges that have accrued thereon. Such a lot, parcel of land, or property,
may be readvertised and resold at any subsequent tax sale for such
delinquent special assessments or installments thereof.
Where suit is instituted by a municipality to foreclose the lien of
special assessments at the request of the owner of real property or his
agent, the corporate authorities shall have the power to provide by
ordinance for the payment by the owner of reasonable costs and expenses
incurred by the municipality in connection with the suit. Any moneys
collected for such purpose shall be expended by the municipality in the
same manner and for the same purposes as provided for in Section 8-1-10.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-99) (from Ch. 24, par. 9-2-99)
Sec. 9-2-99.
Except as otherwise provided in Section 9-2-113, no person
obtaining contracts from the municipality and agreeing to be paid out of
special assessments or special taxes, has any claim or lien upon the
municipality in any event, except from the collection of special
assessments or special taxes made or to be made for the work contracted
for. However, the municipality shall cause collections and payments to be
made with all reasonable diligence. If it appears that such an assessment
or tax cannot be levied or collected, the municipality, nevertheless, is
not in any way liable to a contractor in case of failure to collect the
assessment or tax, but, so far as it can legally do so, with all reasonable
diligence, it shall cause a valid assessment or assessments, or special
taxes, to be levied and collected to defray the cost of the work until all
contractors are fully paid. Any contractor is entitled to the summary
relief of mandamus or injunction to enforce the provisions of this section.
The municipal treasurer shall keep a separate account of each special
assessment warrant number, and of the money received thereunder.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-100) (from Ch. 24, par. 9-2-100)
Sec. 9-2-100.
Except as otherwise provided in Section 9-2-113, any work or
other public improvement, to be paid for in whole or in part by special
assessment or special taxation, when the expense thereof will exceed $10,000,
shall be constructed by contract let to the lowest responsible bidder in
the manner prescribed in this Division 2. Such contracts shall be approved
by the president of the board of local improvements.
In case of any work which it is estimated will not cost more than $10,000,
if after receiving bids it appears to the board of local improvements that
the work can be performed better and cheaper by the municipality, the
corporate authorities of the municipality shall perform that work and
employ the necessary help therefor. The cost of that work by the
municipality in no case shall be more than the lowest bid received.
(Source: P.A. 96-138, eff. 8-7-09.)
(65 ILCS 5/9-2-101) (from Ch. 24, par. 9-2-101)
Sec. 9-2-101.
Except as otherwise provided in Section 9-2-113, if the
ordinance provides for alternate specifications for the kind, nature,
character, and description of a proposed improvement, or the materials to
be used in its construction, and more than one estimate has been prepared,
then the assessing officer or commissioners appointed to make the
assessment shall make his or their report and assessment roll, based upon
the highest estimate of the cost of the proposed improvement.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-102) (from Ch. 24, par. 9-2-102)
Sec. 9-2-102.
Except as otherwise provided in Section 9-2-113, within 90
days after judgment of confirmation of any special assessment or special
tax, levied in pursuance of this Division 2, has been entered, if there is
no appeal perfected, or other stay of proceedings by a court having
jurisdiction, or in case the judgment for the condemnation of any property
for any such improvement, or the judgment of confirmation as to any
property is appealed from, then, if the petitioner files in the cause a
written election to proceed with the work, notwithstanding the appeal, or
other stay, steps shall be taken to let the contract for the work in the
manner provided in this Division 2. If the judgment of condemnation or of
confirmation of the special tax or special assessment levied for the work
is appealed from, or stayed by order of a court
having jurisdiction, and the petitioner files no such election, then the
steps provided in this Division 2 for the letting of the contract for the
work shall be taken within 15 days after the final determination of the
appeal, or the determination of the stay, unless the proceeding is
abandoned as provided in this Division 2.
(Source: P.A. 84-551.)
(65 ILCS 5/9-2-103) (from Ch. 24, par. 9-2-103)
Sec. 9-2-103.
Except as otherwise provided in Section 9-2-113, notice shall
be given by the board of local improvements that bids will be received for
the construction of such an improvement, either as a whole or in such
sections as the board shall specify in its notice, in accordance with the
ordinance therefor. This notice shall state the time of opening of the
bids, and shall further state where the specifications for the improvement
are to be found, and whether the contracts are to be paid in cash or in
bonds, and if in bonds, then the rate of interest the vouchers or bonds
shall draw. The notice shall be published at least twice, not more than 30
nor less than 15 days in advance of the opening of the bids, in one or more
newspapers designated by the board of local improvements in an order
entered in its records, published in the municipality, or, if no newspaper
is published therein, then in one or more newspapers with a general
circulation within the municipality. In municipalities with less than 500
population in which no newspaper is published, publication may instead be
made by posting a notice in 3 prominent places within the municipality.
Proposals or bids may be made either for the work as a whole or for
specified sections thereof. All proposals or bids offered shall be
accompanied by cash, or by a check payable to the order of the president of
the board of local improvements in his official capacity, certified by a
responsible bank,
for an amount which shall not be less than 10% of the
aggregate of the proposal, or by a bid bond, for an amount which shall be not
less than 10% of the aggregate of the proposal. These proposals or bids
shall
be delivered to
the board of local improvements. That board, in open session, at the time
and place fixed in the specified notice, shall examine and publicly declare
the proposals or bids. However, no proposals or bids shall be considered
unless accompanied by such a check or cash.
(Source: P.A. 91-296, eff. 1-1-00.)
(65 ILCS 5/9-2-104) (from Ch. 24, par. 9-2-104)
Sec. 9-2-104.
Except as otherwise provided in Section 9-2-113, the
successful bidder for the construction of such an improvement shall be
required to enter into bond in a sum equal to one-third of the amount of
his bid with sureties to be approved by the president of the board of local
improvements. This bond shall be filed with the board of local
improvements, or where there is no board of local improvements, with the
municipal clerk. When entering into the contract for the construction of an
improvement the bond shall provide that the contractor shall well and
faithfully perform and execute the work in all respects according to the
complete and detailed specifications, and full and complete drawings,
profiles, and models therefor, and according to the time and terms and
conditions of the contract, and also, that the bidder and contractor shall
promptly pay all debts incurred by him in the prosecution of the work,
including those for labor, and materials furnished.
Suit may be brought on the bond in case of default, or failure to pay
these debts promptly, by and in the name of the municipality for all
damages sustained either by the municipality, or by any person interested
or for the damages sustained by the municipality and all parties in
interest, or by any beneficiary or party interested, in the name of the
municipality for the use of the party interested as beneficial plaintiff,
to recover for the labor and materials furnished. However, in no case shall
costs be adjudged against the municipality in any suit brought by any party
in interest wherein the municipality is the nominal, but not the
beneficial, plaintiff.
In advertising for bids or proposals for the construction of such an
improvement, the board of local improvements shall give notice that such a
bond will be required, and all bids or proposals shall contain an offer to
furnish such a bond upon the acceptance of such a bid or proposal.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-105) (from Ch. 24, par. 9-2-105)
Sec. 9-2-105.
Except as otherwise provided in Section 9-2-113, the board of
local improvements may reject any and all proposals or bids, should they
deem it best for the public good. If the board is of the opinion that a
combination exists between contractors, either to limit the number of
bidders, or to increase the contract price, and that the lowest bid is made
in pursuance thereof, the board shall reject all proposals or bids. The
board may reject the bid of any party who has been delinquent or unfaithful
in any former contract with the municipality. It shall reject all proposals
or bids other than the lowest regular proposals or bids of any responsible
bidder and may award the contract for the specified work or improvement to
the lowest responsible bidder at the prices named in his bid. Such an award
shall be recorded in the record of its proceedings. Such an award, if any,
shall be made within 20 days after the time fixed for receiving bids.
If no award is made within that time, another advertisement for
proposals or bids for the performance of the work, as in the first
instance, shall be made, and thereafter the board shall proceed in the
manner above provided in this Division 2. Such a re-advertisement shall be
deemed a rejection of all former bids, and thereupon the respective checks
and bonds corresponding to the bids so rejected shall be returned to the
proper parties. However, the check accompanying any accepted proposal or
bid shall be retained in the possession of the president of the board until
the contract for doing the work, as hereinafter provided, has been entered
into either by the lowest responsible bidder or by the owners of a majority
of the frontage, whereupon the certified check shall be returned to the
bidder. But if that bidder fails, neglects, or refuses to enter into a
contract to perform that work or improvement, as provided in this Division
2, the certified check accompanying his bid and the amount therein
mentioned, shall be declared to be forfeited to the municipality, and shall
be collected by it and paid into its fund for the repairing and maintenance
of like improvements. Any bond forfeited may be prosecuted, and the amount
due thereon collected and paid into the same fund.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-106) (from Ch. 24, par. 9-2-106)
Sec. 9-2-106.
Except as otherwise provided in Section 9-2-113, whenever any
contract has been awarded to any bidder for the construction of any
waterworks system, bridge, or viaduct referred to in Section 9-2-19, the
bid of the party to whom the contract has been awarded and the award
therefor shall be treated as provisional and shall not be binding upon the
party to whom the contract is awarded, or upon the municipality, until the
levying of the tax provided for in Section 9-2-38 has been authorized by
the electors of that municipality voting at an election to be held as
provided in Section 9-2-38. The provisions of this Section 9-2-106 shall
not apply to any city having a population of 500,000 or more.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-107) (from Ch. 24, par. 9-2-107)
Sec. 9-2-107.
Except as otherwise provided in Section 9-2-113, any owner or
person interested in any of the property assessed and any bidder shall be
entitled to a hearing before the board on any question connected with any
such award.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-108) (from Ch. 24, par. 9-2-108)
Sec. 9-2-108.
Except as otherwise provided in Section 9-2-113, a notice of
such an award of contract shall be published in one or more newspapers,
designated by the board of local improvements in an order entered in its
records, published in the municipality, or, if no newspaper is published
therein, then in one or more newspapers with a general circulation within
the municipality. In municipalities with less than 500 population in which
no newspaper is published, publication may instead be made by posting a
notice in 3 prominent places within the municipality.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-109) (from Ch. 24, par. 9-2-109)
Sec. 9-2-109.
Except as otherwise provided in Section 9-2-113, the owners
of a majority of the frontage of the lots and land upon the street wherein
the work is to be done, or their agents, who take oath that they are such
owners or agents, shall not be required to present sealed proposals or
bids, but, within 10 days after the first publication of the notice of such
an award, may elect to take the work, and enter into a written contract to
do the whole work at 10% less than the price at which the contract has been
awarded.
Should those owners fail to elect to take the work, and to enter into a
written contract therefor within 10 days, or to commence the work within 30
days after the first publication of the award, and to prosecute the work
with diligence, the board of local improvements shall enter into a contract
with the original bidder, to whom the contract was awarded, at the prices
specified in his bid.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-110) (from Ch. 24, par. 9-2-110)
Sec. 9-2-110.
Except as otherwise provided in Section 9-2-113, if such
original bidder fails or refuses for 20 days after the first publication of
the notice of award, or in case a contract is made with the owners, and
default by them, then, within 10 days after notice that the owners are in
default, to enter into a contract, which shall be simultaneously executed
by the municipality and signed by the president of the board of local
improvements and attested by the municipal clerk under the municipal seal,
then the board of local improvements, without further proceedings, shall
again advertise for proposals or bids, as in the first instance, and award
the contract for the work to the then regular lowest bidder. The bids of
all persons, and the election of all owners as specified in Section 9-2-109
who have failed to enter into the contract as provided in this Division 2,
shall be rejected in any bidding or election subsequent to the first for
the same work.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-111) (from Ch. 24, par. 9-2-111)
Sec. 9-2-111.
Except as otherwise provided in Section 9-2-113, if the
owners or contractors, who may have taken any contract, do not complete the
work within the time mentioned in the contract, or within such further time
as the board of local improvements may give them, the board may relet the
unfinished portions of that work, after pursuing the formalities prescribed
hereinbefore for the letting of the whole in the first instance.
All contractors, contracting owners included, at the time of executing
any contract for such public work, shall execute a bond to the satisfaction
and approval of the board of local improvements of the municipality, in
such sum as the board deems adequate, conditioned for the faithful
performance of the contract. The sureties shall justify, before some person
competent to administer an oath, in double the amount mentioned in that
bond, over and above all statutory exemptions.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-112) (from Ch. 24, par. 9-2-112)
Sec. 9-2-112.
Except as otherwise provided in Section 9-2-38, the board of
local improvements in cities of 500,000 and over, may appoint an engineer
for the board, and such assistant engineers, clerks, and inspectors as may
be necessary to carry into effect the purposes of this Division 2.
The board is hereby authorized to make or cause to be made, the written
contracts, and receive all bonds authorized by this Division 2, and to do
any other act, expressed or implied, that pertains to the execution of the
work provided for by such an ordinance. The board shall fix the time for
the commencement of the work under such an ordinance and for the completion
of the work under all contracts entered into by it. This work shall be
prosecuted with diligence thereafter to completion and the board may extend
the time so fixed from time to time, as they may think best for the public
good. The work to be done pursuant to such contracts in all cases must be
done under the direction and, except where the assessment is divided into
installments, to the satisfaction of the board of local improvements, and
all contracts made therefor must contain a provision to that effect, and
also express notice that in no case, except as otherwise provided in the
ordinance, or the judgment of the court, will the board, or municipality,
except as otherwise provided in this Division 2, or any officer thereof, be
liable for any portion of the expenses, nor for any delinquency of persons
or property assessed.
The acceptance by the board of any improvement shall be conclusive in
the proceeding to make the assessment, and in all proceedings to collect
the assessment, or installments thereof, on all persons and property
assessed therefor, that the work has been performed substantially according
to the requirements of the ordinance therefor. But if any property owner is
injured by any failure so to construct the improvement, or suffers any
pecuniary loss thereby, he may recover the amount of the injury in a civil
action against the municipality making the improvement, if the action is
commenced within one year from the date of the acceptance of the work by
the board of local improvements.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-113) (from Ch. 24, par. 9-2-113)
Sec. 9-2-113.
In any case where an improvement is to be constructed with
the aid and assistance of any agency of the Federal Government, or any
other governmental agency, the provisions of Sections 9-2-100 through
9-2-112 shall not apply where they conflict with this section. The board of
local improvements in cities having a population of 500,000 or more and the
corporate authorities in municipalities having a population of less than
500,000 may proceed at any time within 90 days after the judgment of
confirmation has been entered in the construction of the work. Within 90
days after the judgment of confirmation the board of local improvements in
cities having a population of 500,000 or more and the corporate authorities
in municipalities having a population of less than 500,000, shall adopt a
resolution determining to proceed with the construction of the work,
publish the resolution within 10 days in one or more newspapers published
in the municipality, or, if no newspaper is published therein, then in one
or more newspapers with a general circulation within the municipality. In
municipalities with less than 500 population in which no newspaper is
published, publication may instead be made by posting a notice in 3
prominent places within the municipality.
Ten days after the publishing of this resolution a copy thereof,
properly certified, shall be filed in the court in which the judgment of
confirmation was entered. This resolution shall be authority for the
issuing of the warrant to the collector for the collection of the
assessment. Each assessment shall draw interest from the date of passage of
the resolution of intention to proceed with the work, as provided in
Sections 9-2-48 through 9-2-51.
After this resolution has been filed and a warrant issued to the
collector for the collection of the assessment, the municipality may issue
bonds or vouchers to anticipate the collection of the unpaid portions of
all installments of the assessment, including the first installment if it
has not been certified delinquent, for the purpose of applying the proceeds
of the bonds toward paying the cost of the improvement, including all
expenses of making, levying, collecting the assessment and engineering and
attorneys' fees. These bonds if issued shall be sold for not less than par
and accrued interest and the proceeds used for that purpose, or the bonds
may be issued, for not less than par and accrued interest, in payment for
materials, labor, or services.
No person furnishing materials or supplying labor for the construction
of any such local improvement shall have any claim or lien against the
municipality except from the collection of the special assessments or
special taxes made or to be made for that work, or from the proceeds of the
sale of bonds to anticipate the collection of the same in case such bonds
have been sold.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-114) (from Ch. 24, par. 9-2-114)
Sec. 9-2-114.
Except as otherwise provided in Section 9-2-117, within 30
days after the final completion and, where required, acceptance of the
work, as provided in Section 9-2-112, the board of local improvements shall
have the cost thereof, including the cost of engineering services,
certified in writing to the court in which the assessment was confirmed,
together with an amount estimated by the board to be required to pay the
accruing interest on bonds or vouchers issued to anticipate collection.
Thereupon, if the total amount assessed for the improvement upon the public
and private property exceeds the cost of the improvement, all of that
excess, except the amount required to pay such interest as is provided for
in this Division 2, shall be abated and the judgment reduced
proportionately to the public and private property owners and shall be
credited pro rata upon the respective assessments for the improvement under
the direction of the court.
In case the assessment is collectible in installments, this reduction
shall be made so that all installments shall be equal in amount, except
that all fractional amounts shall be added to the first installment so as
to leave the remaining installments in the aggregate equal in amount and
each a multiple of $100. If prior to the entry of the order abating and
reducing the assessment the assessment has been certified for collection
pursuant to the provisions of Section 9-2-76, and any of the installments
of the assessment so certified for collection have become due and payable,
the reduction and abatement above referred to shall be made pro rata upon
the other installments. The intent and meaning of this is that no property
owner shall be required to pay to the collector a greater amount than his
proportionate share of the cost of the work and of the interest that may
accrue thereon.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-115) (from Ch. 24, par. 9-2-115)
Sec. 9-2-115.
In every assessment proceeding in which the assessment is
divided into installments, the board of local improvements shall state in
the certificate whether or not the improvement conforms substantially to
the requirements of the original ordinance for the construction of the
improvements, and shall make an application to the court to consider and
determine whether or not the facts stated in the certificate are true.
Thereupon the court, upon such an application, shall fix a time and place
for a hearing upon the application, and shall record the application. The
time of this hearing shall be not less than 15 days after the filing of the
certificate and application. Public notice shall be given at least twice of
the time and place fixed for that hearing by publishing in a newspaper, in
the same manner and for the same period as provided in this Division 2 for
publishing notice of application for the confirmation of the original
assessment, the publication of this notice to be not more than 30 nor less
than 15 days before the day fixed by the order for that hearing.
At the time and place fixed by the notice or at any time thereafter, the
court shall proceed to hear the application and any objection which may be
filed thereto within the time fixed in the order. Upon that hearing the
specified certificate of the board of local improvements shall be prima
facie evidence that the matters and things stated are true, but if any part
thereof is controverted by objections duly filed thereto, the court shall
hear and determine the objections in a summary manner and shall enter an
order according to the fact.
(Source: P.A. 79-1361.)
(65 ILCS 5/9-2-116) (from Ch. 24, par. 9-2-116)
Sec. 9-2-116.
If upon the hearing the court finds against the allegations
of the certificate, it shall enter an order accordingly. The board of local
improvements shall then procure the completion of the improvement in
substantial accordance with the ordinance. The board, from time to time,
may file additional or supplemental applications or petitions in respect
thereto, until the court eventually is satisfied that the allegations of
the certificate or applications are true, and that the improvement is
constructed in substantial accordance with the ordinance.
If before the entry of such an order upon such a certificate there has
been issued to the contractor in the progress of any such work, bonds to
apply upon the contract price thereof, that contractor or the then owner or
holder of those bonds, shall be entitled to receive in lieu thereof new
bonds of equivalent amount, dated and issued after the entry of that order.
Nothing contained in Sections 9-2-114 through 9-2-116 shall apply to any
proceedings under Sections 9-2-72 and 9-2-73, or either of them, for the
confirmation of new assessments, levied to pay for the cost of work already
done.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-117) (from Ch. 24, par. 9-2-117)
Sec. 9-2-117.
Where an improvement has been constructed with the aid of any
agency of the Federal government, or other governmental agency, the
provisions of Sections 9-2-114 through 9-2-116 shall not apply except as to
the manner of the final hearing. In that case, upon completion of the
project the board of local improvements shall adopt a resolution accepting
the project as constructed in full conformance with the ordinance and
specifications therefor and approving the cost of the work upon its
completion as being in compliance with the ordinance and specifications.
Whereupon a certified copy of this resolution shall be filed in the court
in which the judgment of confirmation was entered and a hearing had upon
the cost and completion in the same manner as is provided in Sections
9-2-114 through 9-2-116.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-118) (from Ch. 24, par. 9-2-118)
Sec. 9-2-118.
The board of local improvements shall designate someone to
carefully inspect the entire work done pursuant to any such proceeding and
contract, and the materials therefor, during the progress of the work, to
the end that the contractor shall comply fully and adequately with all the
provisions of the ordinance, and of the contract under which the work is to
be done, and the specifications therefor. Upon the complaint of any
property owner that the work or materials do not comply with those
requirements, the president of the board of local improvements shall either
examine the work and materials himself, or designate some member of the
board to do so. The president of the board shall make a personal
examination, and certify in writing as to the result thereof. This written
certificate shall be filed with the papers pertaining to the board, and
shall be open to public inspection at any time.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-119) (from Ch. 24, par. 9-2-119)
Sec. 9-2-119.
For the purpose of anticipating the collection of the
second and succeeding installments, provided for in this Division 2, a
municipality may issue bonds, payable out of these installments, bearing
interest at a rate specified in the ordinance referred to in Section 2-9-10
of the Illinois Municipal Code and not more than the rate the installments
of the assessment against which the bonds are issued bear,
payable annually and signed by such officers as may be by ordinance
prescribed. Bonds shall be issued in sums of $100, or some multiple
thereof, and shall be dated and draw interest from the date of their
issuance. Each bond shall state on its face out of which installment it is
payable, and shall state, by number or other designation, the assessment to
which that installment belongs. The principal of these bonds shall not
exceed, in the aggregate, the amount of the deferred installments, and
shall be divided into as many series as there are deferred installments.
However, if there is a surplus to the credit of any such installment
which is not required for the payment of any vouchers or bonds issued
against that installment, that surplus shall be applied toward the payment
of any outstanding vouchers or bonds already issued or to be issued, as the
case may be, against any other installment or installments.
Each series shall become due at some time in the year in which the
corresponding installment will mature, the date to conform, as nearly as
may be, to the time when that installment will be actually collected. This
time shall be estimated and determined by the municipal officers issuing
the bonds. But it is lawful to provide in the case of any one or more of
the bonds in any series, that that bond or bonds shall not become due until
some subsequent date, not later than December 31 next succeeding the
January in which the installment against which that series is issued will
mature.
) ss
County of .......)
The .... of .... in .... County, Illinois, for value received, promises
to pay to the bearer on (insert date)
the sum of .... dollars, with interest thereon from date hereof, at the rate of
....%, payable annually on presentation of the coupons hereto annexed.
Both principal and interest of this bond are payable at the office of
the treasurer of said .... of .....
This bond is issued to anticipate the collection of a part of the ....
installment of special assessment No. .... levied for the purpose of ....
which installment bears interest from (insert date), and this bond and the interest thereon are payable solely out of the
installment when collected.
Dated (insert date).
The bond may have coupons attached to represent the interest to accrue
thereon.
In lieu of the bonds described in this Section, a municipality may issue
bonds of the type described in Section 9-2-127, but all bonds issued under
any one special assessment proceeding must be of the same type.
This amendatory Act of 1971 is not a limit upon any municipality which
is a home rule unit.
(Source: P.A. 91-357, eff. 7-29-99.)
(65 ILCS 5/9-2-120) (from Ch. 24, par. 9-2-120)
Sec. 9-2-120.
The court having jurisdiction of the original assessment
proceeding is authorized at any time after the assessment has been
confirmed to extend the time of payment of the assessment, or any
installment thereof, whether due or not due, heretofore or hereafter
levied, and in case securities have been issued, to refund the securities
and past due interest thereon, heretofore or hereafter issued in
anticipation of the collection of the assessment or any installment thereof
levied under the provisions of this Division 2, or any part thereof, and
past due interest thereon (unless such past due interest is waived). In
cases where no securities have been issued, the provisions of this section
as to refunding securities shall not apply but the court, on petition of
the municipality, has jurisdiction to extend the time of payment of the
assessment. Securities not due may be refunded only when the holders
thereof surrender the securities in exchange for refunding securities
issued in lieu thereof, or deposit the securities as hereinafter provided
and agree to accept payment therefor in cash in an amount not exceeding the
par value thereof, together with accrued interest. This payment is to be
made out of the proceeds of the sale by the municipality of those refunding
securities. All securities against any installment to be refunded shall be
so surrendered or deposited.
The specified court is hereby vested with authority to divide any
assessment or any installment or installments thereof into a greater number
of installments than was originally provided for in the order confirming
the assessment and to fix the amount of each installment, if, in its
judgment, such a re-division into a greater number of installments is for
the best interest of all parties concerned.
As used in this section and Sections 9-2-121 through 9-2-124,
"securities" means bonds, coupons (except bonds or coupons issued under
Sections 9-2-127 through 9-2-129) and vouchers, public benefit vouchers,
and warrants and accrued interest.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-121) (from Ch. 24, par. 9-2-121)
Sec. 9-2-121.
Whenever it is desired to extend the time of payment of any
assessment or any of the installments thereof and issue refunding
securities, any municipality that has issued securities in anticipation of
the collection of the special assessment levied under the provisions of
this Division 2, upon a petition of 75% of the holders of any securities
issued against any assessment or any installment or installments thereof
addressed to the corporate authorities of the issuing municipality, shall
adopt an ordinance directing and providing for the extension of the time of
payment of the assessment or any of the installments thereof and the sale
and exchange of refunding securities in anticipation of the collection of
the special assessment or any of the installments thereof the time of
payment of which is to be extended. The ordinance so adopted shall direct
the filing of a petition in the court having jurisdiction of the original
assessment. In the ordinance, the municipality shall establish a date of
issue of those refunding securities and this date of issue shall be also
the date from which interest on those refunding securities shall run and
from which interest on the assessment so extended shall run. The ordinance
for this refunding shall refer to the original assessment proceeding and no
estimate or recommendation by the board of local improvements shall be
required.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-122) (from Ch. 24, par. 9-2-122)
Sec. 9-2-122.
The court shall hear the proceeding in a summary manner
without a jury and there shall be no hearing on benefits or on any legal
objections not arising subsequent and incidental to the proceeding provided
for in Sections 9-2-120 through 9-2-124. No judgment confirming any such
proceeding shall be entered until all unpaid securities have been either
deposited in the court or with some depository under an escrow agreement
approved by the court. The petition shall set forth the amount of the
assessment or installments to be extended, the date of confirmation of the
original assessment, the rate of interest of the original assessment, the
amount of cash on hand in the particular assessment or installments, the
unpaid securities or other obligations to be refunded, the date of maturity
of the unpaid securities, and the rate of interest the unpaid securities
bear. This petition shall also state that the holders of the securities
issued in anticipation of the collection of the assessment or installments,
will surrender their securities in exchange for refunding securities to be
issued under the provisions of Sections 9-2-120 through 9-2-124, or accept
in payment thereof an amount not exceeding the par value thereof, with
accrued interest thereon. This petition shall also state what assessment or
installments thereof are desired to be refunded, the desired maturity and
the rate of interest of the extended installments, and the maturity,
amount, and rate of interest of the refunding securities sought to be
issued.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-123) (from Ch. 24, par. 9-2-123)
Sec. 9-2-123.
Accompanying the petition there shall be filed an assessment
roll setting forth a description of the lots, blocks, tracts, and parcels
of land assessed in the original proceeding, the total amount of the unpaid
installments, and the interest thereon proposed to be extended against each
tract, the amount, number and due date of each installment of the proposed
extended assessment.
The assessment as extended shall
be collected in the same manner as the original assessment.
When this petition is filed it shall be presented to the court and if
found to be in proper form the court shall set the petition for hearing at
such date as will enable the clerk of the court to give at least 10 days'
notice of the hearing thereon, and it is the duty of the clerk to publish a
notice at least twice, not more than 30 nor less than 15 days before the
date set for hearing, in one or more newspapers published in the
municipality, or, if no newspaper is published therein, then in one or more
newspapers with a general circulation within the municipality. In
municipalities with less than 500 population in which no newspaper is
published, publication may instead be made by posting a notice in 3
prominent places within the municipality. This notice shall set forth the
filing of the petition, the docket and warrant number of the assessment and
the installment or installments thereof proposed to be extended and the
number of installments in which it is proposed to divide the extended
assessment. The notice shall also state when and where the court will hear
objections to the petition.
At this hearing the court may extend the time of payment of one or more
installments of the assessment, change the number of installments in which
the assessment is divided, and subject to the provisions of Sections
9-2-120 through 9-2-124, provide for the details of the issuance of the
refunding securities, in accordance with the prayer of the petition, and
enter an order confirming the assessment as extended.
Any property owner may pay the original assessment or any installment to
be extended within 10 days after the entry of such an order. Upon the
expiration of 10 days after the entry of such an order the corporate
authorities shall issue the refunding securities authorized by the order of
the court, but the delivery of the refunding securities shall be
simultaneous with the surrender of the securities to be refunded or paid.
The securities so surrendered shall be immediately cancelled. The
collection and payment of the extended assessment and the securities issued
under Sections 9-2-120 through 9-2-124 shall be in the manner as now
provided by law.
(Source: P.A. 79-1361.)
(65 ILCS 5/9-2-124) (from Ch. 24, par. 9-2-124)
Sec. 9-2-124.
Any assessment and all installments, the time for collection
of which has been extended, shall continue to be a lien on the land
assessed the same as in the original assessment and the refunding
securities issued under the provisions of Section 9-2-120 through 9-2-124
shall be payable therefrom.
Whenever the refunding of securities and the extending of the time of
the payment of assessments or installments thereof include assessments or
installments past due and these assessments or installments or any part
thereof have been returned delinquent, withdrawn, or forfeited as provided
by law, the court, in the order extending the time of payment and
authorizing the refunding of the securities, shall order the county
collector to withdraw those assessments or installments from the delinquent
list and order the proper officers to release all property forfeited or
withdrawn on account of those assessments or installments, the time of
payment of which is to be extended, by a proper entry upon the tax sale and
judgment record of the county. The county clerk shall charge the security
holders a fee of 35 cents for each such service rendered by him in
connection therewith.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-125) (from Ch. 24, par. 9-2-125)
Sec. 9-2-125.
Whenever, in a proceeding under Sections 9-2-120 through
9-2-124, the refunding of securities and the extending of the time of
payment of any assessment or installments thereof include an assessment or
installments past due and the property against which the past due
assessment or installments or any part thereof were levied has been sold at
a sale of property to enforce the collection of the past due assessment to
the municipality levying the assessment and the municipality has not paid
the purchase price at that sale and a certificate of purchase has been
issued and delivered to the municipality, this past due assessment or
installments or any part thereof shall be extended, and the securities
issued to anticipate their collection shall be refunded, as in the case of
an assessment returned delinquent, withdrawn, or forfeited, and the lien of
the original assessment and of the certificate of purchase shall be
continued and preserved by the assessment as extended.
In such a case the court in which the proceeding is pending, in the
order extending the time of payment and authorizing the refunding of the
securities, shall order the municipality levying the assessment to present
its certificate of purchase to the county clerk. The county clerk shall
cancel this certificate by endorsing thereon the words "cancelled by
assessment as extended" and shall enter a note of such cancellation upon
his tax, judgment, sale redemption, and forfeiture record. Where this
certificate or evidence thereof has been recorded with the recorder of
deeds or registered with the registrar of titles the court shall order the
county clerk to issue a certificate to the municipality showing the legal
description of all lots, blocks, tracts, and parcels of land against which
a certificate or evidence thereof has been recorded or registered and
reciting the cancellation of the certificate of purchase by virtue of the
extension of the assessment and refunding of the securities. This
certificate shall be filed by the municipality with the recorder
or the registrar of titles, as the case may be. Thereupon the lien of that
assessment as extended shall stand in lieu of the lien of the original
assessment and of the certificate of purchase, and the assessment as
extended shall be collected in the same manner as the original assessment.
The county clerk shall receive for his services rendered as set forth in
this section a fee of 35 cents for each certificate so cancelled. This fee,
together with the fees of the recorder and of the registrar of
titles shall be paid by the security holders.
(Source: P.A. 83-358.)
(65 ILCS 5/9-2-126) (from Ch. 24, par. 9-2-126)
Sec. 9-2-126.
Whenever any voucher, bond or interest coupon issued by a
municipality in anticipation of the collection of special assessments under
any of the provisions of this Division 2 has been lost, destroyed or stolen
and proof is made to the official of the municipality charged with making
payments on the voucher, bond or interest coupon that the loss, theft or
destruction occurred while the voucher, bond or interest coupon was owned
by and in possession of the claimant, such official shall issue or cause to
be issued and delivered to the claimant a duplicate of such voucher, bond
or interest coupon alleged to have been lost, destroyed or stolen after
first indorsing on the duplicate all payment of principal and interest made
on the original voucher, bond or interest coupon. However, the claimant
shall prior to issuance of any such duplicate execute and deliver to the
municipality a bond in a penalty at least double the amount of the
principal of such voucher, bond or interest coupon alleged to have been
lost, destroyed or stolen with sufficient security to be approved by the
municipal official, conditioned to indemnify the municipality against all
claims by any other person on account of such voucher, bond or interest
coupon and against all costs and expenses by reason thereof.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-127) (from Ch. 24, par. 9-2-127)
Sec. 9-2-127.
In lieu of the bonds authorized in Section 9-2-119, the
municipality upon the written request of the holders of all of the
outstanding and unpaid vouchers issued in payment of the work, may issue
and deliver to such voucher holders, in exchange for such vouchers, bonds
provided for in this Section 9-2-127, provided that prior to the receipt of
such request the municipality has not issued or has not made any commitment
to issue any bonds the funds from which are to be used toward paying such
outstanding and unpaid vouchers in full. The bonds shall be dated as of and
shall draw interest from the date of their issuance, except when issued in
exchange for vouchers theretofore issued in payment of the work. In such
latter case the bonds shall be issued in the principal amount of the unpaid
balance of the vouchers and shall bear the same date as the vouchers for
which they are exchanged or the date to which interest was last paid on the
vouchers, and the bonds shall draw interest from such date. The bonds shall
be issued at not less than their par value. The bonds shall be executed by
such officers as may be prescribed by ordinance of such municipality, with
the corporate seal attached. The bonds shall bear interest at a rate specified
in the ordinance referred to in Section 2-9-10 of the Illinois Municipal
Code and of not more than the rate the installments of the assessment against
which the bonds are issued bear. The bonds shall recite
specifically that they are payable solely and only from the assessment
levied for the payment of the cost of the improvement, designating the
improvement for which the assessment has been levied, and shall mature on
or before December 31 next succeeding the January 2 on which the last
installment shall mature. Interest coupons attached to the bonds shall bear
the official or facsimile signatures of the same officers who signed the
bonds and shall be made payable at the office of the treasurer of the
municipality. The bonds shall be numbered consecutively beginning with
number one upwards and shall be payable in their numerical order and
redeemable prior to maturity in numerical order as hereinafter provided.
Each of the bonds issued pursuant to this Section 9-2-127 shall bear a
legend on the face of the bond printed in bold face type and in a paragraph
by itself to the effect that the bond is one of a series of bonds which are
to be paid and redeemed in numerical order and not on a pro-rata basis.
As used in this Section and in Sections 9-2-128 and 9-2-129, "treasurer"
with respect to municipalities in which a comptroller is elected or
appointed means treasurer or comptroller.
This amendatory Act of 1971 is not a limit upon any municipality which
is a home rule unit.
(Source: P.A. 82-642.)
(65 ILCS 5/9-2-128) (from Ch. 24, par. 9-2-128)
Sec. 9-2-128.
The bonds authorized in Section 9-2-127 may be in the
following form:
Dollars
....
County of ....
KNOW ALL MEN BY THESE PRESENTS, That the .... of ...., in the County of
...., State of Illinois, hereby acknowledges itself to owe, and for value
received promises to pay to the BEARER, the sum of .... Dollars ($....) on
the .... day of ....,...., but subject to prepayment at the par value
hereof at any time as hereinafter provided, together with interest thereon
at the rate of .... per cent (....%) per annum, from date hereof until
paid, payable on the .... day of ....,...., and annually thereafter on the
.... day of .... in each year on presentation and surrender of the interest
coupons hereto attached.
Both principal and interest on this bond are payable at the office of
the treasurer of said .... of ...., in lawful money of the United States of
America.
This bond is issued in exchange for part of the vouchers issued in
payment of the work done under Special Assessment No. ...., levied for the
purpose of ...., which assessment bears interest from the .... day of
....,...., and this bond and the interest thereon are payable solely out of
the installments of the assessment when collected.
THIS BOND IS ONE OF A SERIES OF BONDS WHICH ARE TO BE PAID AND REDEEMED
IN NUMERICAL ORDER AND NOT ON A PRO-RATA BASIS.
The bonds in the series, aggregating .... Dollars ($....), are numbered
from .... to .... inclusive, bonds numbered .... to .... being of the
denomination of $.... each, and bonds numbered .... to .... being of the
denomination of $.... each.
By the terms of the statute and ordinance authorizing these bonds,
whenever there shall be sufficient funds in the hands of the treasurer of
the .... of ...., after the payment of all interest due on the bonds, and
after the establishment of such reserve, if any, as the treasurer in his
discretion may deem advisable to pay interest to become due at the next
interest coupon date, to prepay one or more of the bonds, then it is the
duty of such treasurer to call and pay such bond or bonds. The treasurer
shall cause notice of such call for prepayment to be published in some
newspaper of general circulation in the .... of ...., Illinois, not less
than 5 nor more than 30 days prior to the date fixed for prepayment. If no
newspaper is published in the municipality, such notice shall be published
in a newspaper with a general circulation in the municipality, and if there
be no such newspaper, such notice shall be posted in at least 3 prominent
places within the municipality. This bond will cease to bear interest on
and after the date so fixed for prepayment. The presentation of the bond
will waive the necessity of giving notice of its call for payment. Bonds
shall be paid in numerical order beginning with the lowest numbered
outstanding bond.
IN TESTIMONY WHEREOF, the .... of .... has caused its corporate seal to
be hereto affixed, and this bond to be signed by the officers prescribed by
ordinance, and the coupons hereto attached to be signed by such officials
by their original or facsimile signatures, which officials, if facsimile
signatures are used, do adopt by the execution hereof as and for their
proper signatures their respective facsimile signatures appearing on the
coupons, all as of the .... day of ....,.....
....
....
Interest coupons which may be attached to bonds authorized in this
section may be in the following form:
Coupon No. ....
$....
On the .... day of ....,...., unless the bond to which this coupon is
attached shall have theretofore been called for payment at an earlier date
and payment made or provided for,
The .... of .... in the County of ...., State of Illinois, will pay to
BEARER .... Dollars ($....), out of funds realized from the collections of
Special assessment No. .... of the municipality, at the office of the
treasurer of the municipality, for interest due on that day on its
improvement bond dated as of the .... day of ....,....
BOND NO. .....
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-129) (from Ch. 24, par. 9-2-129)
Sec. 9-2-129.
The municipality shall have the right to call and pay the
bonds authorized in Section 9-2-127, or any number thereof, in the
following manner:
Whenever there are sufficient funds in the hands of the treasurer to
redeem one or more of the bonds, after the payment of all interest due, and
after the establishment of such reserve, if any, as the treasurer in his
discretion may deem advisable to pay interest to become due at the next
interest coupon date, the treasurer, by publication or posting of notice as
provided in this section, shall call and pay such bond or bonds. The
treasurer shall cause notice of such call for payment to be published in a
newspaper published in the municipality, or if no newspaper is published
therein, then in a newspaper with a general circulation within the
municipality, and if there be no such newspaper, then by posting in at
least 3 prominent places within the municipality. The notice shall specify
the number or numbers of the bonds called, designating the assessment
against which the bonds have been issued, and directing presentation of
such bonds for payment and cancellation, and indicating that interest will
cease on the bonds not less than 5 nor more than 30 days from the date of
publication of such notice or posting, and thereafter the bonds shall cease
to bear interest. The presentation of any bond to the treasurer for payment
shall waive the necessity of giving notice of its call for payment.
The treasurer upon accumulation of sufficient funds shall pay one or
more bonds and shall call and pay such bonds. Any bondholder or holder of
any interest coupon appertaining to any bond, after giving reasonable
notice, shall be entitled to summary relief by mandamus or injunction to
enforce these provisions.
When bonds are issued under Section 9-2-127, all collections of the
special assessment installments and all interest collected shall constitute
a single fund which shall be applied first to the payment of interest due,
and to the establishment of such reserve, if any, as the treasurer in his
discretion may deem advisable to pay interest to become due at the next
interest coupon date, and then to the redemption and payment of bonds as
provided herein. However, in municipalities having a population of less
than 500,000, where the ordinance for the improvement provides for the
collection of costs, collections made on the first installment shall be
used first to pay such costs, and any surplus shall be used to pay bonds
and interest thereon as provided herein. Provision as to redemption and
call of the bonds shall be inserted in each of the bonds issued in
accordance with the provisions of this Section 9-2-129.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-130) (from Ch. 24, par. 9-2-130)
Sec. 9-2-130.
The bonds may be sold, or paid to the contractor having the
contract for the improvement for which the assessment was levied, at not
less than their par value and interest accrued to time of delivery, whether
sold, or paid to the contractor.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-131) (from Ch. 24, par. 9-2-131)
Sec. 9-2-131.
Payment for any improvement done or performed under the
provisions of this Division 2, to be paid for out of any special assessment
or special tax levied in installments, as provided in this Division 2, may
be made in the bonds provided for in this Division 2. In the event payment
is made in the bonds authorized under Section 9-2-119, the first
installment of such special assessment or special tax shall be paid to the
person entitled thereto on the contract for that work. If this first
installment is not collected when payments fall due, vouchers therefor may
be issued, payable out of the first installment when collected. These
vouchers shall bear interest at the rate specified in the ordinance referred
to in Section 9-2-10 of the Illinois Municipal Code for bonds and not more
than the rate the installments of the assessment against which the vouchers
are issued bear, payable
annually, and shall be signed by such officers as may be prescribed by
ordinance.
In the event payment is made in the bonds authorized under Section
9-2-127, the first installment of such special assessment or special tax
and all other installments thereof shall be held and used to pay the bonds
and interest thereon as provided in Section 9-2-127.
However, in municipalities having a population of less than 500,000,
where the ordinance for the improvement provides for the collection of
costs, such costs shall be first paid out of this first installment and may
be included in and evidenced by vouchers issued as provided in this Section
9-2-131.
This amendatory Act of 1971 is not a limit upon any municipality which
is a home rule unit.
This amendatory Act of 1972 is not a limit upon any municipality which
is a home rule unit.
(Source: P.A. 82-642.)
(65 ILCS 5/9-2-132) (from Ch. 24, par. 9-2-132)
Sec. 9-2-132.
Any property owner may pay his assessment wholly or in part,
either before or after it is due, and whether or not the assessment has
been withdrawn from collection or the property assessed has been sold to
any municipality or forfeited to the State for nonpayment of that
assessment, with the bonds or vouchers heretofore or hereafter issued under
this Division 2 on account of that assessment, applying, however, bonds
issued under Section 9-2-119 and vouchers of each series only to the
payment of the installments to which they relate. If bonds issued under
Section 9-2-127 are used to make such payments, such bonds may be applied
to the payment of any and all installments, but only such of those bonds
may be used as are next in numerical order of redemption at the time of
making such payments. In making such payments, the vouchers and bonds shall
be taken at their par value and interest accrued to the date of making the
payment. All vouchers and bonds received in payment of such an assessment
shall be cancelled by the officer receiving the vouchers, or bonds, as of
the date of their receipt, and then deposited with the treasurer or the
comptroller, as the case may be, of the municipality issuing the vouchers
or bonds.
However, when the amount of the assessment is less than that of a bond
or voucher, the officer receiving the same shall issue a receipt for the
balance which shall entitle the owner to the same rights, except as to
negotiability, as if the receipt were the original bond or voucher in the
amount of the balance. Any such indorsement on any such bond or voucher
shall be made by writing or stamping across the face thereof the words
"payments upon this bond (or voucher) are listed upon the back."
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-133) (from Ch. 24, par. 9-2-133)
Sec. 9-2-133.
When any municipality provides by ordinance for the
construction of a waterworks system, any portion of the cost of which is to
be paid by special assessment and a direct annual tax is authorized by a
vote as provided in Section 9-2-38, in order to secure the payment of the
cost of that construction, the contractor and holders of the bonds that may
be issued in payment of that cost, in the manner provided in this Division
2, shall have a lien upon the waterworks system, and upon the income to be
derived from its operation, to secure the payment of the amounts due them
respectively. This lien shall be to the fullest extent that the
municipality may be authorized by law to create. Upon a request in writing
of the contractor for the construction of such a waterworks system, or of
the holders of a majority in amount of the specified bonds, the
municipality shall convey by a deed of trust in the nature of a mortgage
the waterworks system so to be constructed, and all the property, both real
and personal, pertaining thereto. Such a deed of trust shall secure the
payment of the assessment for public benefit or of the bonds as the
contractor or holders of the bonds may elect. The trustees in such a deed
of trust shall be selected by the contractor or the holders of a majority
in amount of such bonds. The provisions of this section shall not apply to
any city having a population of 500,000 or more.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-134) (from Ch. 24, par. 9-2-134)
Sec. 9-2-134.
The entire proceeds arising from the operation of such
waterworks system shall be paid into the municipal treasury and shall be
kept in a separate fund to be known as the "waterworks fund." After the
payment therefrom of the necessary running and operating expenses of the
waterworks system, the balance from time to time shall be credited by the
municipal treasurer upon the assessment levied against the municipality for
public benefits and the respective installments thereof, and shall be
applied toward the payment of the cost of the waterworks system in the
manner provided by this Division 2. Until the bonds so issued to pay the
cost of the construction of the waterworks system and the interest thereon
have been fully paid, the municipal treasurer shall not pay any warrant
drawn on the "waterworks fund" for any other purpose except for the payment
of the necessary operating expenses of the waterworks system.
In case such a waterworks system is used and operated to supply water
for any existing distributing system, the entire proceeds derived from the
operation of the waterworks system and the distributing system so supplied
with water shall be apportioned and divided in proportion to the original
cost of the distributing system, and the cost of the waterworks system.
These costs shall be determined by the municipal clerk. The portion of such
income that is so determined to arise from the operation of the waterworks
system shall be paid to the municipal treasurer and placed in the
"waterworks fund" and used only in the manner specified in this section.
The provision of this section shall not apply to any city having a
population of 500,000 or more.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-135) (from Ch. 24, par. 9-2-135)
Sec. 9-2-135.
No person accepting the vouchers or bonds as provided in this
Division 2 shall have any claim or lien upon the municipality in any event
for the payment of his vouchers or bonds or the interest thereon, except
from the collection of the assessment against which the vouchers or bonds
are issued. The municipality, nevertheless, shall not be in any way liable
to the holders of these vouchers or bonds in case of a failure to collect
the assessment, but with all reasonable diligence, so far as it can legally
do so, it shall cause a valid special assessment or a special tax, as the
case may be, to be levied and collected, to pay these bonds and vouchers,
until all bonds and vouchers are fully paid. Any holder of vouchers or
bonds, or his assigns, shall be entitled to summary relief by way of
mandamus or injunction to enforce the provisions of this section.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-136) (from Ch. 24, par. 9-2-136)
Sec. 9-2-136.
From time to time, as the work under any contract for such an
improvement progresses, upon certificates by the board of local
improvements, or by some officer designated by the board for that purpose,
payments may be made either in money, vouchers, or bonds, as provided in
this Division 2, to apply upon the contract price, reserving, however, a
sufficient amount upon each of the payments to properly secure, in the
judgment of the board, the faithful performance of the contract. This
reserve shall be paid over at such time and on such conditions as the board
shall fix, after the specified work has been completed or accepted.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-137) (from Ch. 24, par. 9-2-137)
Sec. 9-2-137.
The board of local improvements before the crediting of the
excess as provided for in Section 9-2-114, shall estimate an amount deemed
sufficient to make up any probable deficiency of interest, in the event
that from any cause, collections of interest may prove insufficient to meet
the interest to be paid on the bonds until they mature as hereinbefore
provided. This estimated amount shall be deducted out of the installments
as an item of expense before crediting rebates of excess as directed in
this Division 2 and shall be used for no other purpose than to make up such
a deficiency until the bonds are fully paid, both principal and interest.
Any balance remaining of this estimated amount after the principal and
interest of the bonds are fully paid may be used to reimburse the corporate
fund for any advances made from this fund on account of costs of the
special assessment or special tax or other expenses of the improvement for
which the special assessment or special tax is levied.
However, in municipalities having a population of 500,000 or more, no
deduction of this estimated amount out of the installments shall be made
where the ordinance providing for the assessment provided that a certain
sum not to exceed 5% of the amount of that special assessment or special
tax shall be applied as provided in Sections 9-2-138 and 9-2-139, or in
case such a municipality, at any time before the crediting of such excess,
shall annually appropriate or set aside a fund sufficient in amount to meet
all estimated deficiencies in interest which may arise during the year for
which the fund is provided.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-138) (from Ch. 24, par. 9-2-138)
Sec. 9-2-138.
If, after final settlement with the contractor for any
improvement and after full payment of all vouchers or bonds except those
bonds and interest coupons not presented for payment, although called and
for which funds are available and reserved, within the period of time
specified in Section 9-1-5, issued on account of that improvement, there is
any surplus remaining in the special assessment or special tax above the
specified payments and above the amount necessary for the payment of
interest on those vouchers or bonds, such surplus shall be applied to
reimbursing the public benefit fund for any amounts paid from such fund on
account of the improvement. If, after the public benefit fund has been
reimbursed, a surplus still remains, the proper authorities of the
municipality shall declare at once a rebate upon each lot, block, tract, or
parcel of land assessed, of its pro rata proportion of that surplus. Such
rebate shall be paid to the owner of record of each such lot, block, tract,
or parcel at the time of the declaration of the rebate. Should any
additional funds be collected after the original rebate is declared, the
municipality shall not be required to declare a supplemental rebate for 5
years from the date the original rebate is declared. The municipality may
deduct for its cost and expenses for declaring and making any rebate not
more than 5% of the amount declared to be rebated. The board of local
improvements shall keep and exhibit publicly in its office, an index of all
warrants upon which rebates are due and payable and upon proper proof, the
warrants shall be repaid to the persons entitled thereto.
However, whenever any municipality having a population of 500,000 or
more has appropriated or set aside a fund sufficient in amount to meet all
estimated deficiencies in interest, cost of making, levying, and collecting
a special assessment or special tax, and of letting and executing
contracts, advertising, clerical hire, engineering and inspection, court
costs and fees of commissioners in condemnation proceedings incurred in
such a proceeding and has provided, in the ordinance providing for the
assessment, that a certain sum not to exceed 5% of the amount of the
assessment or special tax shall be applied toward the payment of the
specified and other costs of making and collecting the assessment, the
money collected in the fund created by this 5% so added as hereinbefore
authorized shall be used to pay all deficiency in interest in the warrant,
and the balance shall be used to reimburse the corporate funds for advances
made from the corporate funds on account of costs of the special assessment
or special tax or other expenses of the improvement for which the special
assessment or special tax was levied.
(Source: Laws 1965, p. 2969.)
(65 ILCS 5/9-2-139) (from Ch. 24, par. 9-2-139)
Sec. 9-2-139.
The costs and expenses of maintaining the board of local
improvements, for paying salaries of the members of the board, and the
expense of making and levying special assessments or special taxes and of
letting and executing contracts, and also the entire cost and expense
attending the making and return of the assessment rolls and the necessary
estimates, examinations, advertisements, and like matters, connected with
the proceedings provided for in this Division 2, including the court costs
and the fees to commissioners in condemnation proceedings, which are to be
taxed as provided in this Division 2, shall be paid by the municipality out
of its general corporate fund.
However, in municipalities having a population of less than 500,000, the
municipality, in the ordinance providing for the prescribed assessment, may
provide that a certain sum, not to exceed 6% of the amount of this
assessment, shall be applied toward the payment of the specified and other
costs of making and collecting this assessment. In municipalities having a
population of less than 500,000, the estimate of cost of the improvement
may also provide an item setting forth a reserve for deficiency in interest
not to exceed 6% of the amount of the assessment.
The limitation in the preceding paragraph shall not apply to the costs
of engineering and inspection connected with any local improvement, but
these costs in municipalities having a population of less than 500,000 may
be included in the cost of the improvement to be defrayed by special
assessment or special tax.
In municipalities having a population of 500,000 or more, the
municipality, in the ordinance providing for the prescribed assessment, may
provide that a certain sum not to exceed 5% of the amount of this
assessment, as finally determined after the completion of the improvement
in accordance with Sections 9-2-114 through 9-2-116, shall be applied (but
only by way of reimbursement of the general corporate fund as hereinafter
in this Section provided) toward the payment of the cost of making,
levying, and collecting the special assessment or special tax, and of
letting and executing contracts, advertising, clerical hire, engineering
and inspection, court costs and fees of commissioners in condemnation
proceedings incurred in the proceeding and deficiency in interest in the
matter of the special assessment or special tax. If the part of the
assessment levied on account of the expenses specified in this paragraph,
exceeds 5% of the entire assessment as finally determined in accordance
with Sections 9-2-114 through 9-2-116, but does not exceed 5% of the
assessment as originally levied and filed in court, that excess shall not
constitute any objection to a judgment of confirmation of the assessment.
But no larger sum on account of the expenses specified in this paragraph
than 5% of the assessment as finally determined in accordance with Sections
9-2-114 through 9-2-116, shall be treated as a part of the cost of the
improvement to be certified by the board of local improvements in
accordance with Sections 9-2-114 through 9-2-116, and if the part of the
assessment originally levied on account of the expenses specified in this
paragraph exceeds 5% of the entire assessment as finally determined in
accordance with that Section, any such excess shall be treated as a part of
the excess to be abated in accordance with the provisions of Sections
9-2-114 through 9-2-116.
Such a deficiency in interest, if any, shall be first paid out of the
fund so created by this 5% so added as in this Section authorized. The
application of this fund toward the payment of the expenses specified in
the preceding paragraph shall be only by paying over and transferring the
balance of the fund after the payment of such a deficiency in interest, to
the general corporate fund of the municipality for reimbursement for
expenses of the improvement for which the assessment is levied, theretofore
paid out of that general corporate fund.
(Source: P.A. 76-758.)
(65 ILCS 5/9-2-140) (from Ch. 24, par. 9-2-140)
Sec. 9-2-140.
Appeals from final judgments or orders of any court made in
the proceedings provided for by this Division 2, may be taken in the manner
provided in other civil cases, by the municipality or by any of the owners
or parties interested in land taken, damaged, or assessed therein. However,
no appeal may be taken after 30 days from the entry of the final judgement
or order. Such an appeal may be prosecuted jointly, and upon a joint bond,
or severally, and upon several bonds, as may be specified in the order
fixing the amount and terms of such bonds.
(Source: P.A. 76-1407.)
(65 ILCS 5/9-2-141) (from Ch. 24, par. 9-2-141)
Sec. 9-2-141.
After the expiration of the 30 day period allowed for filing
a notice of appeal under this Division 2, an appeal from any such judgment
may be filed in the manner provided in other civil cases on petition or
application of owners or parties interested in the property affected
thereby, as shown by the record, at any time after the disposition of the
last remaining objections to the confirmation, if any, prior to the first
day of June following the entry of the judgment.
However, if the warrant for collection as to any parcel is not certified
for collection so that an application for judgment of sale may be made in
the year following the entry of the judgment, leave to appeal as to that
parcel, on application, may be granted by the reviewing court within the
period of one year after the entry of the judgment.
In every case there shall be filed with the clerk of the reviewing
court, with the application for leave to appeal, an affidavit by the
appellant or his agent setting forth the time when the warrant for
collection, as to the property, was so certified, and further setting forth
that the person to whom the notice of the filing of assessment roll as to
the property, as shown by the record, did not receive the notice, or
otherwise learn of the pendency of the proceedings for the confirmation of
the assessment until less than 10 days before the entry of default against
his property in the court below. In all such cases the notice of appeal
shall contain a statement that it is filed pursuant to leave granted by the
reviewing court under authority of this Division 2 and the notice of appeal
shall be filed and served on or before the dates hereinabove fixed.
(Source: Laws 1967, p. 3762.)
(65 ILCS 5/9-2-142) (from Ch. 24, par. 9-2-142)
Sec. 9-2-142.
Any municipality, not already controlled by this Division 2,
if it so determines by ordinance, may adopt the provisions of this Division
2, and where it has so adopted this Division 2, it has the right to take
all the proceedings provided for and to have the benefit of all the
provisions of this Division 2.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-143) (from Ch. 24, par. 9-2-143)
Sec. 9-2-143.
Whenever, immediately prior to January 1, 1942, authority of
law existed in corporate authorities to levy special assessments or special
taxes for local improvements, and for that purpose to use the proceedings
provided by Article 9 of an act entitled "An Act to provide for the
incorporation of cities and villages," approved April 10, 1872, as amended,
or by "An Act concerning local improvements," approved June 14, 1897, as
amended, such corporate authorities are authorized to make use of the
provisions of this Division 2 for the purpose, with the same effect, and to
the same extent as heretofore authorized to use the provisions of either
mentioned act. Any such corporate authorities as may be on and after
January 1, 1942, authorized by law to levy such special assessments or
special taxes, whether otherwise expressly authorized thereto or not, may
make use of the provisions of this Division 2 in like manner.
If, in any such case, a board of local improvements, as required in this
Division 2, does not exist, the corporate authorities shall take such steps
for a public hearing, on the subject of the proposed improvement, to be
paid for by special assessment or special taxation, as are required in this
Division 2 of the board of local improvements, and they shall act as such a
board in the manner provided in this Division 2, as nearly as may be, both
in originating the improvement and in executing the work and making payment
therefor.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-2-144) (from Ch. 24, par. 9-2-144)
Sec. 9-2-144.
The laws subsisting immediately prior to January 1, 1942, the
time of the taking effect of this Division 2, shall continue to apply to
all proceedings for the condemnation of land, or the confirmation of
special assessment or special taxes for local improvements, which were
pending in any court in this state at the time of the taking effect of this
Division 2, and to all proceedings for the collection of any deficiency
under past levies already made under any law existing at the time of the
taking effect of this Division 2, and also to all proceedings for new
assessments made in lieu of others annulled before this Division 2 took
effect, by order of some court.
Whenever any installment of an assessment confirmed under prior acts
matures, proceedings to return the installment delinquent, and to collect
the installment shall conform to the provisions of this Division 2.
Whenever any bond issued under "An Act concerning local improvements,"
approved June 14, 1897, as amended, matures, proceedings to refund or
enforce its payment shall conform to the provisions of this Division 2, so
far as they are applicable.
Nothing in this Division 2 shall be construed to repeal any of the laws
relating to civil service, and nothing in this Division 2 shall be
construed to repeal or modify any of the rules of the civil service
commission of the city of Chicago adopted pursuant to the civil service
laws, and nothing in this Division 2 shall be construed to repeal Division
84 of Article 11.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/Art. 9 Div. 3 heading)
(65 ILCS 5/9-3-1) (from Ch. 24, par. 9-3-1)
Sec. 9-3-1.
Any municipality may make a local improvement whenever the
public necessity requires such improvement, subject only to the limitations
prescribed in this Division 3. This Division 3 shall not be construed as
repealing any other laws with respect to local improvements, but shall be
considered as an additional grant of power for the purposes herein set out.
Any number of streets, avenues, lanes or alleys, or any other public
places, or parts thereof, to be improved may be included in one proceeding
(even though they may be intersected by previously improved streets,
avenues, roads or alleys which are not included in the proceeding) where
they are contiguous or part of a connected system with reciprocal benefits.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-2) (from Ch. 24, par. 9-3-2)
Sec. 9-3-2.
In this Division 3, the following terms have the meaning
ascribed to them unless the context indicates otherwise:
"Municipality" means any city, village, or incorporated town.
"Attorney" means the attorney employed by the municipality to furnish
the necessary legal services in connection with any local improvement to be
constructed under this Division 3.
"Engineer" means the engineer employed by the municipality to prepare
the necessary plans, estimates, and specifications, and supervise
construction of any local improvement to be constructed under this Division
3.
"Assessed valuation" means the value of the property as shown on the tax
collectors' record for the last year in which taxes were levied.
"Assessor" or "assessing officer" means the county or township official
who performs the duties of assessor.
"Committee on local improvements" means the committee created pursuant
to Section 9-3-3 consisting of the presiding officer of the corporate
authorities of the municipality and an attorney and an engineer.
"Local improvements" means and includes the improving, widening or
extending of any street, avenue, lane, alley or other public place by
grading, paving, repaving, resurfacing, and constructing curbs, gutters,
storm sewers, sanitary sewers, water mains, walks, gas mains, street lights
and all necessary appurtenances thereto and otherwise improving the same,
or repairing of curbs, gutters, storm sewers, sanitary sewers, water mains,
walks, gas mains, street lights and all necessary appurtenances thereto and
otherwise improving the same.
"Prime Commercial Rate" means such prime rate as from time to time is
publicly announced by the largest commercial banking institution located
in this State, measured in terms of total assets.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-3) (from Ch. 24, par. 9-3-3)
Sec. 9-3-3.
Whenever the corporate authorities of any municipality
deem it necessary to undertake any local improvement, within the
corporate limits, a resolution shall be adopted describing the public
property to be so improved. Such resolution shall also establish a
committee on local improvements consisting of the presiding officer of
the corporate authorities, an attorney and an engineer. Such resolution
shall direct the committee on local improvements to proceed in the
preparation of plans, specifications, estimate of cost, and an ordinance
for the improvement. Proceedings to make a local improvement also may be
instituted whenever the owners of more than one-half of the property
abutting on any street, avenue, lane, alley or other public place, or
portion thereof, petition the corporate authorities of any municipality
to make any local improvement within the corporate limits. If such
petition is presented the corporate authorities shall adopt a resolution
describing the public property to be so improved and directing the
committee on local improvements, consisting of the same membership as
described above in this section, to proceed in the preparation of plans,
specifications, estimate of cost and an ordinance for the improvement.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-4) (from Ch. 24, par. 9-3-4)
Sec. 9-3-4.
The corporate authorities of any municipality may contract for
the services of an attorney and an engineer, who shall be members of the
committee on local improvements, to prepare the necessary plans, plats,
profiles, estimates, specifications, and all other details for any of such
improvement. The engineer may be any person registered to practice
engineering in the State of Illinois. Such municipality shall provide for
the payment for services of the attorney and engineer either from the
assessments to be levied against the property benefited to pay the cost of
such improvement, or from its general funds, or from the motor fuel tax
fund, or from State or Federal funds allocated to the municipality, or from
any other available public or private fund, or from any combination of the
foregoing sources of funds.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-5) (from Ch. 24, par. 9-3-5)
Sec. 9-3-5.
Upon the adoption of a resolution determining to make the
improvement by the corporate authorities, the committee on local
improvements shall proceed with the preparation of plans, specifications
and estimate of cost of the improvement. Upon completion, the plans,
specifications and estimate of cost, shall be filed in the office of the
recording officer of such municipality. The plans and specifications shall
be in sufficient detail to enable a competent engineer to direct
construction thereof, and in sufficient detail to advise any person
interested of the general nature, character and type of the improvement.
The estimate of cost shall set forth in one item the estimated amount to be
paid the contractor. A second item shall include the cost of making and
collecting the assessment, engineering inspection, attorneys' fees and
other costs, which second item shall in no event exceed 12% of the
estimated contract price as set out in the first item above mentioned. The
plans, specifications and estimate of cost shall be accompanied by:
(1) A certificate executed by the members of the committee on local
improvements setting forth the boundaries of the area probably benefited by
such improvement. The establishment of the boundaries of the area probably
benefited shall have no relation to the levy of an assessment against
property benefited. Such boundaries are to be used merely for the
determination of an area in which protests may be filed against the
construction of the improvement. Assessments shall be levied against all
property benefited regardless of whether or not such property is located
within the boundaries of the area;
(2) A certificate executed by the County Clerk setting forth the lots,
tracts and parcels of real estate that have been forfeited for delinquent
taxes either for general taxes or special taxes, or both, within the
boundaries of the area as set forth in the certificate required by
subdivision (1) of this section;
(3) A certificate executed by the assessing officer of the county to
show the assessed valuation of each lot, tract and parcel of real estate
located within the boundaries of the area set forth in the certificate
required under subdivision (1) of this section;
(4) A certificate executed by any officer of the municipality setting
forth the names and addresses of all persons owning lots, tracts and
parcels of real estate within the boundaries of the area probably benefited
by such improvement as shown on the tax collector's records for the last
year in which taxes were levied.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-6) (from Ch. 24, par. 9-3-6)
Sec. 9-3-6.
After the filing of the plans, specifications and estimate of
cost, as provided in Section 9-3-5, the corporate authorities shall, by
resolution, set a day and hour for a public hearing upon the proposed
improvement which shall not be less than 10 days after the filing of the
plans, specifications and estimate of cost. Notice of the time and place of
the public hearing shall be sent by mail directed to the person who paid
the general taxes for the last preceding year on each lot, tract and parcel
of real estate within the boundaries of the area probably benefited, not
less than 5 days prior to the date set for the public hearing. The notice
in addition to the time, date and place of the public hearing shall contain
a general description of the proposed improvement including the estimated
cost and a statement that the plans and specifications are on file with the
recording officer of the municipality for public inspection.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-7) (from Ch. 24, par. 9-3-7)
Sec. 9-3-7.
At the time and place fixed for the public hearing, the
corporate authorities shall meet and hear anyone desiring to be heard upon
the subject of the proposed improvement. In case any person objects to the
proposed improvement or any of the elements thereof, the corporate
authorities shall adopt a new resolution abandoning the proposed scheme or
adhering thereto, or changing, altering, or modifying the extent, nature,
kind or character, without a further public hearing thereon, as it
considers most desirable. Thereupon, if the proposed improvement is not
abandoned, the committee on local improvements shall change or amend the
plans, specifications and estimate of cost if it deems it necessary and
prepare an ordinance authorizing and directing the improvement to be made.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-8) (from Ch. 24, par. 9-3-8)
Sec. 9-3-8.
After the public hearing has been held as provided in Section
9-3-7, and after the plans, specifications and estimate of cost have been
filed in the office of the recording officer of the municipality, the
corporate authorities shall by resolution, set a date for consideration and
passage of the ordinance, and direct that notice be given by posting or
publication of the date set for consideration of said ordinance. Such
notice, if posted, shall be posted in not less than 3 public places in such
municipality not less than 10 days prior to the date set for such
consideration. If published such notice shall be published at least once in
a newspaper published and of general circulation in the municipality, if
there be such a newspaper, not less than 10 days prior to the date set for
the consideration of the ordinance. If no newspaper of general circulation
is published within the municipality then no publication shall be necessary
and notice given by posting will be sufficient. Such notice by posting or
by publication shall describe generally the improvement proposed to be
made, set the boundaries of the area probably benefited, and provide that
the owners of record of real estate within the area may at any time, prior
to the date set for consideration of the ordinance authorizing the
improvement, protest in writing against the construction of such
improvement. If the owners of record of 70% or more of the area of the real
estate located within the area described as probably benefited, file a
written protest in the office of the recording officer (to be designated in
the posting or publication) prior to the date set for consideration of the
ordinance authorizing the improvement, then the corporate authorities of
such municipality shall not pass the ordinance, and the improvement shall
not again be initiated for a period of 6 months.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-9) (from Ch. 24, par. 9-3-9)
Sec. 9-3-9.
On the date set for consideration and passage of the ordinance,
the corporate authorities shall convene, consider the ordinance, examine
the certificates submitted with the ordinance in relation to the area
benefited and consider all protests that have been filed against the
construction of the improvement. The corporate authorities before adoption
of the ordinance shall consider the forfeitures and the valuations shown in
the certificates of the respective lots, tracts and parcels of real estate
within the boundaries of the area probably benefited. If lots, tracts and
parcels of real estate representing 25% or more of such value as shown in
the certificate in sub-section (3) of Section 9-3-5 of the lots, tracts and
parcels of real estate within the boundaries of the area probably benefited
have been forfeited to the State for the non-payment of taxes, either
general taxes or special assessments, or both, then the corporate
authorities shall not adopt the ordinance and shall proceed no further with
the improvement and the same improvement shall not again be initiated for a
period of one year. Further, if 50% or more in number of the lots, tracts
and parcels of real estate within the above described boundaries represent
vacant property and the owners of 50% or more in number of the lots, tracts
and parcels, of real estate file written objections, the corporate
authorities shall proceed no further with the improvement and the same
improvement shall not again be initiated for a period of one year, or if
the estimated cost of the improvement exceeds the assessed full, fair cash
value of the real estate located within the boundaries of the district
probably benefited, as shown by the county assessor's certificate, then the
corporate authorities shall proceed no further with the improvement and the
same improvement shall not be again initiated for a period of one year. If,
however, there is less than 25% of the real estate within the area
forfeited for non-payment of general taxes or special assessments, or both,
and there are less than 50% in number of the lots, tracts and parcels of
real estate within the area vacant, or if 50% or more in number of the
lots, tracts and parcels of real estate within said area are vacant but the
owners of less than 50% of the lots, tracts and parcels of real estate file
objections, and the total estimated cost of the improvement does not exceed
the assessed full, fair cash value of the real estate located within the
area designated as probably benefited, then the corporate authorities shall
be authorized to proceed with the improvement and adopt the ordinance
authorizing and directing the construction thereof.
The corporate authorities shall adjourn from time to time for
consideration of the passage of the ordinance, but not for longer than a
period of 90 days from the date set for hearing thereon. If within 90 days
after the date set for the hearing and consideration of the ordinance such
ordinance is not passed, then such ordinance shall not be passed unless the
improvement is again initiated and a new date set for hearing and
consideration of the ordinance and notice of the date published and posted
as provided in this Division 3.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-10) (from Ch. 24, par. 9-3-10)
Sec. 9-3-10.
The ordinance authorizing and directing the construction of
any local improvement shall describe generally the nature and character of
the improvement and refer to plans, specifications and estimate of cost
thereof on file in the office of the recording officer of the municipality.
It shall not be necessary that the ordinance set forth in detail the
proposed improvement to be made.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-11) (from Ch. 24, par. 9-3-11)
Sec. 9-3-11.
Any local improvement ordinance passed by the corporate
authorities shall be published one time in a newspaper published and of
general circulation in such municipality, if there be one, and if there be
no such newspaper, then such ordinance shall be posted in not less than 3
public places in such municipality. Such ordinance shall not become
effective until 10 days after publication or posting, as the case may be.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-12) (from Ch. 24, par. 9-3-12)
Sec. 9-3-12.
After such ordinance becomes effective the corporate
authorities shall direct some office of such municipality to file a
petition in the circuit court in the county in which such municipality is
situated, or if such municipality is situated in more than one county, and
the proposed improvement lies in more than one county, then in the circuit
court in the county in which the major part of the territory to be affected
thereby is situated. The petition shall be filed in the name of such
municipality, praying that steps be taken to levy a special assessment for
such improvement, in accordance with the provisions of this Division 3. The
circuit court shall have jurisdiction of any proceedings under this
Division 3. Accompanying the petition shall be the following:
(1) A certified copy of the ordinance providing for the construction of
the improvement;
(2) A certificate executed by the assessor to show the assessed value of
each lot, tract, or parcel of real estate listed in the assessment roll
provided for in this Division 3;
(3) An assessment roll prepared by an officer of the municipality
designated by the corporate authorities of the municipality.
Such officer shall prepare an assessment roll, and determine in the
first instance what proportion of the estimated cost of such improvement
will be of benefit to the public and what proportion thereof will be of
benefit to the property, and to apportion the same between the municipality
and property benefited, so that each shall bear its relative equitable
proportion. After having determined such amounts, such officer shall
apportion and assess the amount so found to be of benefit to the property
upon the several lots, tracts and parcels of land in the proportion in
which they will be severally benefited by such improvement. No lot, tract
or parcel of land shall be assessed in a greater amount than it will
actually be benefited. Each lot, tract or parcel of land shall be assessed
separately, in the same manner, as an assessment for general taxation.
However, this requirement shall not apply to property of railroad
companies, or the right of way and franchise of street railway companies,
but the same may be described in any manner sufficient to reasonably
identify the property intended to be assessed. The assessment roll shall
contain a list of all lots, tracts and parcels of land assessed for the
proposed improvement, the amount assessed against each, the name of the
person who paid the taxes on each such parcel during the last preceding
calendar year during which taxes were paid, as ascertained upon
investigation made under the direction of the official making the
assessment roll, and the residence of the person so paying the taxes on
each such parcel, if the same can, on diligent inquiry, be found.
In case of an assessment divided into yearly installments, the amount of
each installment shall also be stated, and the officer making such roll
shall certify under oath that he believes that the amounts assessed against
the public and each parcel of property are just and equitable, and do not
exceed the benefit which will, in each case, be derived from such
improvement, and that no lot, tract or parcel of land has been assessed
more than its proportionate share of the cost of such improvement. Such
assessment roll shall be prima facie evidence of the benefit to each such
lot, tract or parcel of land and to the public as therein set out.
(Source: Laws 1967, p. 3762.)
(65 ILCS 5/9-3-13) (from Ch. 24, par. 9-3-13)
Sec. 9-3-13.
After filing of the petition as provided in Section 9-3-12,
the court shall enter an order setting a date for hearing on the question
of benefits, and direct that notice be given by the committee on local
improvements of the pendency of the proceeding. The notice shall state
generally the nature of the improvement, the pendency of the proceeding,
the time and place of filing the petition therefor, that an assessment roll
has been filed, and the time and place at which an application will be made
for confirmation of the assessment, the same to be not less than 15 days
after the mailing of such notice. Such notice shall be sent by mail,
postpaid, to each person paying the taxes on the respective parcels during
the last preceding year during which taxes were paid, at his residence as
shown in the assessment roll, or if not shown, then to each person so
paying the taxes directed generally to the municipality in which the
improvement is proposed to be made. Such notice shall also state the amount
assessed, the person to whom the same is directed for the improvement
proposed, and the total cost of such improvement, and the total amount
assessed as benefit upon the public, and if the assessment is to be payable
in installments, the number of installments thereof and the rate of
interest it shall bear. An affidavit shall be filed before the final
hearing thereon by the committee on local improvements showing a compliance
with the requirements of this section and also showing that the committee
on local improvements caused to be made under its direction, or that it
made a careful examination of the county collector's books showing the
payments of general taxes during the last preceding year, in which the
taxes were paid thereon, to ascertain the person who last paid the taxes on
the respective parcels, and a diligent search for such person's residence,
and that the assessment roll filed in court correctly states the same as
ascertained by the committee on local improvements, or as ascertained under
its direction. If the report and affidavit shall be found in any respect
wilfully false, the persons making the same shall be guilty of perjury, and
subject to the pains and penalties provided for such offense by the laws of
this State.
In addition to the mailing of the notice, notice shall also be given by
the committee on local improvements at least 15 days prior to the date set
for the hearing by posting notice in at least 4 public places in such
municipality, all of which shall be in the neighborhood of such proposed
improvement, and within the boundaries of the area described as probably
benefited, and as in this Division 3 provided, and by publishing the same
once each week for 2 successive weeks in a daily or weekly newspaper
published in the municipality, the first publication thereof to be at least
15 days prior to the date set for the hearing on benefits, or if there be
no newspaper published and of general circulation in such municipality,
then by publication in a newspaper published in the county and of general
circulation therein. Such notice shall state the pendency of the
proceedings, set forth a brief general description of the nature of the
improvement, refer to the fact that the ordinance for the same is on file
in the office of the municipal clerk for public inspection, together with
plans, specifications and an estimate of cost of the improvements, and that
such municipality has applied to the court, designating the court, for the
levying of a special assessment, that the assessment roll has been filed in
court and stating the date when the hearing thereon will be had, and that
all persons desiring may file objections to the assessment on any
particular lot, parcel or tract before the date set for said hearing, and
may appear at the hearing and make their defense as to the question of
benefits. If the assessment is to be payable in installments, then such
notice shall state the number of installments and the rate of interest the
installment shall bear.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-14) (from Ch. 24, par. 9-3-14)
Sec. 9-3-14.
Any person interested in any real estate to be affected by
such assessment may appear and file objections to the amount assessed
against any such real estate. However, such objection must be filed in
writing in the court in which the petition has been filed within the time
named in the notice, or within such further time as the court may continue
the case, or within such further time as the court may allow.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-15) (from Ch. 24, par. 9-3-15)
Sec. 9-3-15.
The assessment roll as returned by the officers making the
same shall be prima facie evidence of the correctness of the amount
assessed against each lot, tract or parcel of real estate, but shall not be
counted as testimony of any witness or witnesses in the cause. If it is
objected on the part of any property assessed for improvement that it will
not be benefited thereby to the amount assessed thereon, and that it is
assessed more than its proportionate share of the cost of such improvement,
and a jury is not waived by agreement of parties, the court shall impanel a
jury to try the issue, and in such case, except as otherwise ordered by the
court, all such objections shall be tried and disposed of before a jury.
Such assessment roll may be submitted to the jury and may be taken into a
jury room by the jury when it retires to deliberate on its verdict. Either
party may introduce such other evidence that may bear on the issues. The
hearing shall be conducted as in other cases at law and if it shall appear
that the premises of any objector are assessed more than such premises will
be benefited by such improvement, or more than its proportionate share of
the cost of such improvement, the jury shall so find, and shall also find
the amount for which the premises ought to be assessed, and the judgment
shall be rendered accordingly.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-16) (from Ch. 24, par. 9-3-16)
Sec. 9-3-16.
The hearing on benefits in all cases arising under this
Division 3 may be had at such time as the court may designate. Such
proceedings shall have precedence over all other cases in any court where
the same shall be brought, except criminal cases or other cases in which
the public is a moving party.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-17) (from Ch. 24, par. 9-3-17)
Sec. 9-3-17.
The court before which any such proceedings may be pending
shall have authority to modify, alter, change, annul or confirm any
assessment returned as aforesaid and make all such orders as may be
necessary to such improvement according to the principles of this Division
3 and may from time to time, as may be necessary, continue the application
for that purpose.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-18) (from Ch. 24, par. 9-3-18)
Sec. 9-3-18.
No special assessment shall be levied under the provisions of
this Division 3 until the land necessary therefor or rights in land, are
acquired and in possession of any such municipality, except in cases where
proceedings to acquire such land have been begun and have proceeded to
judgment.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-19) (from Ch. 24, par. 9-3-19)
Sec. 9-3-19.
In case any special assessment levied under this Division 3 is
divided into installments under the provisions of this Division 3, the
judgment of confirmation that shall be entered by the court, shall apply to
all of the installments thereof and may be entered in one order.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-20) (from Ch. 24, par. 9-3-20)
Sec. 9-3-20.
The judgment of the court shall be final as to all issues
involved and the proceedings in such case shall be subject to review by
appeal, as hereinafter provided, and not otherwise. However, by mutual
consent the judgment may be vacated or modified notwithstanding the
expiration of 30 days of the rendition of such judgment, except as
hereinafter provided.
Such judgments shall have the effect of several judgments as to each
tract or parcel of land assessed. No appeal from any such judgment shall
invalidate or delay the judgments except as to the property concerning
which the appeal is taken. Each installment of each judgment, shall have
the effect of several judgments. Foreclosure or sale of the property, to
enforce the collection of any one installment, shall not affect the lien
for any subsequent installment.
Such judgments shall be liens on behalf of the municipality making the
improvements and for the payment of which the special assessment is levied
on the property assessed from the date thereof until paid, to the same
extent and of equal force and validity as a lien for general taxes, or
until the property against which any such judgments or installment thereof
has been entered is sold to pay the same, as provided in this Division 3.
Nothing in this section shall interfere with the right of the petitioner
to abandon the proceedings, and for that purpose to vacate such judgments
at any time before commencing the actual collection of such assessment. The
court in which the judgment is rendered may enter an order vacating or
modifying such order of confirmation on motion of the petitioner entered at
any time after the expiration of 30 days from the rendition of such
judgment of confirmation upon a showing by the petitioner that no contract
was let or entered into for the making of such improvement within the time
fixed by law for the letting of the contract, or that the making of such
improvement under the original proceeding was never commenced, or that the
making of such improvement under the proceedings was abandoned. No judgment
entered in such proceedings so dismissed and vacated, shall be a bar to
another like or different improvement. However, after the contract for the
work is entered into, or bonds herein provided for in this Division 3 are
issued, no judgment shall be vacated or modified or any petition dismissed,
nor the collection of the assessment, in any way stayed or delayed, without
the consent of the contractor and bondholders.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-21) (from Ch. 24, par. 9-3-21)
Sec. 9-3-21.
For any special assessment levied under the provisions
of this Division 3 that are annulled by the corporate authorities, or
set aside by any court, or declared to be invalid or void for any reason
whatever, a new assessment may be made and returned, and like notice
shall be given and proceedings had, as herein required in relation to
the first. If any improvement is constructed in accordance with the
provisions of this Division 3, and is accepted by the corporate
authorities, and the special assessment attempted to be levied to pay
the cost of such improvement is annulled, set aside, or declared invalid
or void, then a new special assessment may be made and returned to pay
the cost of the improvement so constructed, or to pay the cost of such
part thereof as the governing body might lawfully authorize to be
constructed, and paid for by special assessment under the provisions of
this Division 3. All parties in interest shall have like rights, and the
corporate authorities and the court shall perform like duties, and have
like power in relation to each such new special assessment, as hereby
given in this Division 3 in relation to the first regular assessment.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-22) (from Ch. 24, par. 9-3-22)
Sec. 9-3-22.
The ordinance for any improvement to be constructed under this
Division 3 may provide that the special assessment to be levied to defray
the cost thereof be divided into installments, not more than 20 in number.
The first installment of the assessment shall be due and payable on January
2 next after the awarding of the contract for the construction of such
improvement. The second installment shall be due one year thereafter, and
so on annually, until all installments are paid. It is hereby made the duty
of the clerk of the corporate authorities, to file in the office of the
clerk of the court in which the assessment was confirmed, a certificate
setting forth the date of the awarding of the contract for the construction
of the improvement. All installments shall bear interest until paid at a
rate set forth in such ordinance and not to exceed the greater of 9% per
annum or 70% of the Prime Commercial Rate in effect at the time of the passage
of said ordinance. Interest on assessments
shall begin to run
from the date of filing of the certificate evidencing the award of the
contract for the construction of the improvement, and the interest on each
installment shall be payable as follows:
On January 2 next succeeding the filing of the certificate evidencing
award of the contract, the interest accrued to that time on all unpaid
installments, shall be due and payable and shall be collected with the
first installment. Thereafter interest on all unpaid installments, then
payable, shall be payable annually, and be due and payable at the same time
as the installment maturing in such year, and be collected therewith. In
all cases, it shall be the duty of the municipal collector, whenever
payment is made on any installment, to collect interest thereon up to the
date of such payment, whether the payment be made at or after maturity. Any
person may at any time pay the whole assessment against any lot, piece or
parcel of land, or any installment thereof, without interest, as
hereinafter provided within 20 days after awarding contract or thereafter,
with interest to the next interest payment date.
(Source: P.A. 82-642.)
(65 ILCS 5/9-3-23) (from Ch. 24, par. 9-3-23)
Sec. 9-3-23.
All contracts awarded by any municipality for the construction
of any improvement authorized and provided for under this Division 3 shall
be payable solely and only out of the assessment levied to pay the cost of
the construction thereof. No person taking any contracts for the
construction of any improvement provided for under this Division 3 shall
have any claim or lien upon such municipality in any event except from the
collection of the special assessments levied for the payment of the cost of
the work. If it appears that such assessment cannot be levied or collected,
such municipality shall not be in any way liable to any such contractor in
case of failure to collect the same, but shall so far as it can legally do
so with all reasonable diligence cause a valid assessment to be made to
defray the cost of the work until any such contractor has been fully paid.
Any contractor shall be entitled to summary relief or mandamus or
injunction to enforce the provisions hereof.
The treasurer of any such municipality shall keep a separate account for
each special assessment.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-24) (from Ch. 24, par. 9-3-24)
Sec. 9-3-24.
All contracts for the construction of any improvement to be
paid by special assessment when the expense thereof exceeds $500 shall be
let to the lowest responsible bidder after advertisement for bids, as
hereinafter provided. However, if aid is received from an agency of the
Federal Government, and the application for such aid is approved by an
agency of the Federal Government, no such letting of bids is required. If
such municipality determines to construct the improvement with the aid from
an agency of the Federal Government, then the corporate authorities of any
municipality shall make such determination by resolution and file a
certified copy of the resolution setting out such determination in the
court in which the judgment on confirmation on the assessment has been
entered. Thereafter such municipality shall be authorized to proceed with
the construction of the improvement without letting a contract therefor, in
the manner hereinafter provided.
Within 90 days after the judgment of confirmation of any special
assessment has been entered and if there is no appeal perfected from
the judgment of confirmation, or the judgment of confirmation as
to any property is appealed from, then if the petitioner files in such
cause a written election to proceed with the work, notwithstanding such
appeal, steps shall be taken to let the contract for such work in the
manner hereinafter provided. If the judgment of confirmation is stayed by
order of a court, or if the petitioner filed no
election to proceed as herein provided, then the steps herein provided for
the letting of the contract for such work shall be taken within 15 days
after final determination of any stay of the proceedings or of any such
appeal, unless the proceedings be abandoned as in this Division 3.
(Source: P.A. 84-551.)
(65 ILCS 5/9-3-25) (from Ch. 24, par. 9-3-25)
Sec. 9-3-25.
Notice for bids for the construction of the improvement shall
be published in at least one issue of a newspaper published and of general
circulation in such municipality, if there is one, and if there is no such
newspaper then by publishing such notice in some newspaper published in and
of general circulation in the county in which such municipality is located.
Such publication shall be made at least 10 days prior to the date fixed for
the opening of bids for such work, and an additional notice may be
published in trade journals or other newspapers as the governing body may
determine. The notice for bids shall state (1) the general nature and
character of the work to be done; (2) the engineer's estimate of the amount
to be paid the contractor, and that no contract will be awarded in excess
thereof; (3) when and where bids will be opened; (4) that plans, profiles
and specifications for such work and form of contract and bond for
completion and maintenance of work are on file in the office of the clerk
of such municipality for public inspection; and (5) that each bidder must
file with his bid cash or a certified check satisfactory to the governing
body in an amount equal to 10% of the estimated amount to be paid the
contractor, such cash or certified check to be held by the municipality as
damages for failure to execute the contract and bond for performance of
such work. Right shall be reserved to reject any or all bids. Such notice
shall also state the number of installments the assessment has been divided
into and the rate of interest the bonds to be issued in anticipation of the
assessment shall bear. Such notice shall be signed by the municipal clerk.
If bonds are to be issued in anticipation of the collection of the
assessments, the corporate authorities shall, prior to the date set for
receiving the bids, fix the rate of interest the bonds are to bear. Such
interest rate shall be one per cent less than the interest rate the
installments of the assessments are to bear. It shall be stated in the
notice whether payment will be made in bonds or cash.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-26) (from Ch. 24, par. 9-3-26)
Sec. 9-3-26.
The committee on local improvements shall meet at the time and
place specified by the corporate authorities for receipt of bids and
publicly open and declare all bids. Any or all bids may be rejected by such
committee on local improvements. If all bids are rejected, new bids may be
requested as in the first instance. Whenever a bid is rejected, the deposit
required to be made shall be returned to the depositor. Contracts when
awarded shall be awarded to the lowest responsible bidder subject to
ratification and approval by the corporate authorities. Contracts may be
awarded by the committee on local improvements at the meeting at which bids
are received, or any adjournment thereof. The committee on local
improvements shall report in writing to the corporate authorities at the
next regular meeting the action that has been taken relative to bids
received. The corporate authorities shall ratify and approve or reject the
action taken and direct the committee on local improvements to execute the
contract on behalf of the municipality, if an award is made, or in case the
award is rejected, to again direct advertisement for bids. No contract
shall be awarded for the construction of any improvement under this
Division 3 after the expiration of one year from the date of confirmation
of the assessment. The municipality shall dismiss and vacate the
confirmation of any such assessment. No contract shall be awarded in excess
of the estimated amount to be paid the contractor.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-27) (from Ch. 24, par. 9-3-27)
Sec. 9-3-27.
Within 20 days after the contract is awarded, the contractor
shall enter into a contract with such municipality for the construction of
the improvement and shall give bond in the full amount of the contract for
the faithful performance of the contract. The contract and bond shall be
submitted to and approved by the committee on local improvements and filed
in the office of the clerk.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-28) (from Ch. 24, par. 9-3-28)
Sec. 9-3-28.
The contract shall be executed by the contractor and the
presiding officer of the corporate authorities and attested by the clerk of
such municipality under the official seal of the municipality. Such
contractor shall supply a surety bond in the full amount of the contract
for the faithful performance thereof. Failure of the contractor to enter
into such contract and give such bond within the 20 days hereinabove
provided for shall constitute a default and the certified check deposited
with his bid shall be deemed forfeited, and the municipality shall again
re-advertise for bids. Any contractor who enters into a contract for the
construction of the improvement and who fails to complete the same within
the time mentioned in the contract, or within such further time as the
corporate authorities grant shall be in default and a contract may then be
relet for the unfinished portions of such work, in the same manner as
provided for advertising for bids in the first instance.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-29) (from Ch. 24, par. 9-3-29)
Sec. 9-3-29.
Immediately upon awarding the contract for the construction of
the improvement, the clerk of any such municipality shall file a
certificate in the court in which the judgment of confirmation was entered
certifying to the fact that the contract has been awarded. The clerk of the
court in which such judgment is rendered shall certify the assessment roll
and judgment to the officers of such municipality authorized to collect
such special assessment, or if there has been an appeal taken then such
clerk of court shall certify such part of the judgments as is not included
in such appeal. Such certificate shall be filed by the officer receiving
the same in his office. With such assessment roll and judgment, the clerk
of the court shall also issue a warrant for the collection of such
assessment. The court may recall such warrants as to all or any part of the
property affected at any time before payment of the assessment or sale of
the property for payment thereof in case the proceedings be abandoned by
the petitioner, or the judgment be vacated or modified, as herein provided,
but not otherwise. Should an appeal be taken on any part of such judgments
and the corporate authorities elect to proceed with the improvement
notwithstanding such an appeal, as provided in this Division 3, the clerk
shall certify such portions of such judgments appealed from time to time,
in the manner above mentioned, as the final judgment is rendered thereon,
and the warrant accompanying such certificate in each case shall be
authority for the collection of so much of the assessment as shall be
included in the portion of the roll thereto attached. The warrant in all
cases of assessment under this Division 3 shall contain a copy of such
certificate of the judgment describing the lots, tracts and parcels of real
estate assessed so far as they shall be contained in the portion of the
roll so certified and the respective amount assessed on each lot, tract or
parcel of real estate, and delivered to the officer authorized to collect
such special assessment.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-30) (from Ch. 24, par. 9-3-30)
Sec. 9-3-30.
Upon receipt of the warrant for the collection of the
assessment it shall be the duty of the collector to immediately give notice
thereof by publishing notice at least once in a daily or weekly newspaper
published and of general circulation in such municipality, if there is one.
If there is no such newspaper, then notice shall be given by posting the
same in 4 places within the area being improved. The published or posted
notice shall indicate that the judgment of confirmation has been entered by
the court and shall describe the improvement for which the assessment has
been levied, that the collector has received the warrant for the collection
of the assessment, that any property owner whose property has been assessed
may pay the assessment in full without interest if it is paid within 20
days from the date of the award. The notice shall also state the number of
installments the assessment has been divided into and the rate of interest
each installment bears, and also shall indicate where payment may be made.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-31) (from Ch. 24, par. 9-3-31)
Sec. 9-3-31.
The construction of such improvement in accordance with the
provisions of the contract shall be under the supervision of the committee
on local improvements, and from time to time, as the work under any
contract for the improvement progresses, certificates may be issued by the
committee on local improvements to the contractor for work completed and
payments may be made to the contractor in amounts not to exceed 85% of the
work constructed and completed by vouchers payable either in cash or bonds
that may be issued, as in this Division 3 provided, upon completion of the
work. All such vouchers shall be signed by the presiding officer of the
municipality, attested by the clerk and registered, numbered and
countersigned by the treasurer. The treasurer shall keep an accurate
register of all such vouchers issued.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-32) (from Ch. 24, par. 9-3-32)
Sec. 9-3-32.
Within 30 days after the completion of the work, the committee
on local improvements shall certify the fact that the work has been
completed and accepted by the corporate authorities of such municipality,
setting forth the total amount due the contractor for the construction of
the work, the amount of the vouchers payable either in cash or bonds that
have been delivered to the contractor from time to time as the work
progressed, and the amount still due the contractor. The corporate
authorities upon receipt of the certificate shall set a date for
consideration and hearing upon the question of whether or not the work has
been completed in substantial compliance with the plans, specifications and
contract for the construction thereof, and shall direct the clerk to give
notice of the date set for the hearing. Such notice shall be published at
least once each week for 2 successive weeks in a daily or weekly newspaper
published and of general circulation in such municipality, if there is such
a newspaper. If there is no such newspaper, then notice shall be given by
posting in not less than 4 public places in such municipality, and in at
least 4 places within the boundaries of the area designated by the
committee on local improvements as probably benefited by the improvement.
The first publication or the first posting of such notice shall be at least
15 days prior to the date fixed for such hearing. Any person interested
may, prior to the date fixed for such hearing, file written objections to
the acceptance of such work, stating specifically the reasons therefor, and
shall have the right to be heard at the time and place fixed by the
governing body to hear and consider the same. At the time and place fixed,
the corporate authorities shall hear any and all objections that have been
filed in writing to the acceptance of the completed work and the corporate
authorities shall have authority to continue the hearing from time to time,
but for a period of not more than 30 days from the date set for such
hearing, to consider written objections filed to the acceptance of the work
and to give all persons an opportunity to be heard thereon. At such hearing
the certificate of the committee on local improvements shall be prima facie
evidence that the matter and things stated therein are true, but if any
parts thereof are controverted by written objections duly filed, the
corporate authorities shall hear and determine the same in a summary manner
and shall enter an order according to the facts. Such order shall be
conclusive upon all parties and no party shall be allowed to review or
reverse the order of the corporate authorities. If upon such hearing the
corporate authorities shall find the allegations of the certificate to be
incorrect, it shall enter an order accordingly and it shall then be the
duty of the committee on local improvements to procure the completion of
such improvement in substantial compliance with the ordinance and the plans
and specifications therefor. The committee on local improvements shall from
time to time file additional or supplemental applications to the corporate
authorities for final acceptance of the work until the corporate
authorities shall eventually be satisfied that the allegations in such
certificates are true and that the improvement has been constructed in
substantial compliance with the plans, specification and ordinance.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-33) (from Ch. 24, par. 9-3-33)
Sec. 9-3-33.
If upon final settlement with the contractor for the
construction of any improvement and after paying all costs of levying,
collecting and making the assessment, which amount shall not under any
circumstances exceed 12% of the estimated contract price, and all bonds and
interest thereon issued, as in this Division 3 provided, except those bonds
and interest coupons not presented for payment, although called and for
which funds are available and reserved, within the period of time specified
in Section 9-1-5, there shall be any surpluses remaining in the special
assessment fund, the corporate authorities of such municipality shall at
once cause a rebate to be declared upon each lot, tract or parcel of real
estate assessed of its pro rata proportion of such surplus. Such rebate
shall be paid to the owner of record of each such lot, block, tract or
parcel at the time of the declaration of the rebate. Should any additional
funds be collected after the original rebate is declared, the municipality
shall not be required to declare a supplemental rebate for 5 years from the
date the original rebate is declared. The municipality may deduct for its
costs and expenses for declaring and making any rebate not more than 5% of
the amount declared to be rebated. All surpluses shall remain in the
special assessment fund until after full payment of all bonds and vouchers
issued in anticipation of the collection of the assessment, and there shall
be no rebate until all such bonds and vouchers have been paid in full, both
as to principal and interest, except those bonds and interest
coupons not
presented for payment, although called and for which funds are available
and reserved, within the period of time specified in Section 9-1-5. The
corporate authorities shall cause to be kept and exhibited publicly in the
office of the clerk of such municipality, an index of all special
assessment accounts or warrants upon which a rebate is due and payable and
upon proper proofs the same shall be repaid to the persons entitled
thereto.
(Source: P.A. 91-357, eff. 7-29-99.)
(65 ILCS 5/9-3-34) (from Ch. 24, par. 9-3-34)
Sec. 9-3-34.
No litigation, suit or proceeding of any kind or character
shall be instituted touching the sufficiency of the plans, specifications,
estimate of the cost, or ordinance authorizing the improvement, unless such
litigation, suit or proceeding is instituted within 15 days after the
adoption of the ordinance by the corporate authorities of such municipality
authorizing and directing the improvement to be made. No litigation, suit
or proceeding of any kind or character shall be instituted to collaterally
attack the final acceptance of the work by the corporate authorities unless
such litigation, suit or proceeding is instituted within 15 days after the
final acceptance of the work by the corporate authorities.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-35) (from Ch. 24, par. 9-3-35)
Sec. 9-3-35.
At any time after 15 days from date of acceptance of the
work by the corporate authorities bonds may be issued to anticipate the
collection of the unpaid portions of the assessment then remaining
unpaid for the purpose of paying the cost of the improvement, including
cost of making and collecting the assessment, engineering, inspection,
attorney's fees and other costs. The bonds may be sold by the corporate
authorities for not less than par and accrued interest to date of
delivery, or such bonds may be issued and delivered to the contractor in
payment of the work at not less than par. The bonds shall be authorized
pursuant to a resolution adopted by the corporate authorities and shall
bear a date not earlier than 20 days after the date of the awarding of
the contract for the construction of the improvement and coupons shall
be attached thereto representing interest due thereon as it matures,
interest to be paid annually. The bonds shall be executed by the
presiding officer of the municipality and attested by the clerk of such
municipality, with the corporate seal attached thereto. The bonds shall
recite specifically that they are payable solely and only from the
assessment levied for the payment of the cost of the improvement,
designating the improvement for which the assessment has been levied,
and shall mature on or before the first day of December next succeeding
the first day of January on which the last installment shall mature, and
shall bear interest at a rate of one per cent less than the installments
of the assessment against which they are issued bears. Interest coupons
attached to the bond shall bear the official or facsimile signatures of
the presiding officer and clerk. The bonds shall be made payable at such
place or places either within or without the State of Illinois, as shall
be declared by resolution of the corporate authorities. The bonds shall
be numbered consecutively beginning with number one upwards and shall be
payable in their numerical order, and redeemable prior to maturity in
numerical order as hereinafter provided. Such bonds shall be registered
by the treasurer of such municipality in a book provided for that
purpose and each bond shall bear the certificate of such registration
and upon the books of such treasurer shall be noted the name of the
holder thereof and his address. Any subsequent holder may cause the same
to be registered in the name of such subsequent holder upon submission
of proper proof of ownership. Such municipality shall have the right to
call and pay the bonds, or any number thereof, in the manner set out in
Section 9-3-36.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-36) (from Ch. 24, par. 9-3-36)
Sec. 9-3-36.
Whenever there are sufficient funds in the hands of the
treasurer after the payment of all interest due and to become due within 6
months, the treasurer shall on the first day of October of any year, or at
any other time there are sufficient funds for that purpose on hand during
the year, give notice by registered mail, addressed to the last registered
holder of the bonds called at the address appearing upon his registry, that
there are funds sufficient to pay the designated bonds and interest thereon
to date 30 days hence from the date of such notice and directing
presentation of such bonds for payment and cancellation, and the bonds
shall cease to bear interest after the expiration of the 30 days and upon
payment and cancellation of the bonds proper entry thereof shall be made
upon the books of the treasurer. The treasurer, upon accumulation of
sufficient funds, as herein provided, shall pay one or more bonds and shall
call and pay such bonds, and any bondholder or holder of any interest
coupon appertaining to any bond shall be entitled to summary relief by
mandamus or injunction to enforce the provisions hereof. In addition to
giving notice by registered mail to the last registered holder of such
bonds, the treasurer shall cause to be published in a newspaper published
and of general circulation in such municipality, if there is such a
newspaper. If there is no such newspaper, the notice shall be given by
posting in at least 3 places within the area designated as probably
benefited by the improvement. Such notice shall be a notice of call and
redemption addressed to all unknown bondholders specifying the number of
the bonds called and designating the assessment against which the bonds
have been issued, and indicating that interest will cease on the bonds 30
days from and after the date of publication of such notice, and thereafter
the bonds shall cease to bear interest. Provisions as to redemption and
call of the bonds shall be inserted in each of the bonds issued in
accordance with the provisions of this Division 3.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-37) (from Ch. 24, par. 9-3-37)
Sec. 9-3-37.
Any deduction in assessments made pursuant to the order of the
court may be added to and become part of the municipality's portion of the
cost of the improvement. The corporate authorities by the adoption of the
resolution may direct the attorney member of the committee on local
improvements to file a motion to authorize the court to add the deduction
to the municipality's portion of the assessment.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-38) (from Ch. 24, par. 9-3-38)
Sec. 9-3-38.
No collateral attack or litigation shall be instituted which
in any way questions the enforceability of the validity of the bonds issued
under the provisions of this Division 3 unless such litigation is
instituted within 15 days after the issue and delivery of the bonds to the
contractor on payment of work, or within 15 days after the issue and
delivery thereof to a purchaser, as in this Division 3 provided.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-39) (from Ch. 24, par. 9-3-39)
Sec. 9-3-39.
The assessment authorized by this Division 3 shall constitute
valid and binding liens upon the respective tracts of property against
which they are assessed from the date of the confirmation of the assessment
until paid, prior to all other claims and liens, and shall be coequal with
the lien for general taxes, and shall not be questioned in any action
or proceeding except on proof of failure to give notice of the hearing on
the question of benefits, unless such suit shall be instituted within 10
days after the confirmation of the assessment roll by the court.
(Source: P.A. 83-345.)
(65 ILCS 5/9-3-40) (from Ch. 24, par. 9-3-40)
Sec. 9-3-40.
Liens shall be enforced and collected independently of any
other provision of the statutes contrary thereto notwithstanding.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-41) (from Ch. 24, par. 9-3-41)
Sec. 9-3-41.
Whenever any assessment has been levied against any real
estate, the assessment or installments thereof shall become delinquent the
first day of July next after the due date thereof and bear interest after
delinquency at the rate as in this Division 3 provided until paid, or until
such real estate is sold for the payment thereof, as in this Division 3
provided. The assessment after delinquency shall continue to be collected
by the authorized collector of any such municipality. Such municipality
shall institute proceedings to foreclose and sell property for the payment
of any assessment, or installment thereof, remaining delinquent 6 months
after delinquency date. Any holder of any bond or of any interest coupon is
entitled to summary relief by mandamus or injunction to enforce the
provisions hereof.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-42) (from Ch. 24, par. 9-3-42)
Sec. 9-3-42.
The corporate authorities by resolution shall direct some
officer of such municipality to file a petition in the name of such
municipality in any court of competent jurisdiction to foreclose the lien
as to the past due assessment, or installment thereof, and cause the real
estate against which such assessment, or installment thereof, is levied to
be sold to pay the same. As many lots, tracts and parcels of land as may be
desired may be joined in one suit so long as the lots, tracts and parcels
of land are delinquent for the same assessment or installment thereof
constituting liens against the real estate created under this Division 3.
Upon filing of the petition, notice shall be given by the clerk of the
court addressed "To All Owners, Parties Concerned and Persons Interested"
in the described tracts of real estate, setting forth a description of the
several tracts of real estate sought to be sold, the pendency of the
proceedings, the docket number of the cause, and stating the term of court
at which the petition will be heard. The notice shall be published by the
clerk of the court in a newspaper published and of general circulation in
the municipality where such real estate is situated if there is such a
newspaper. Otherwise, such notice shall be published in a newspaper
published and of general circulation in the county. Such notice shall be
published at least 30 days prior to the date set for the hearing in the
cause. The petition and notice shall give the court full jurisdiction of
all the parties interested as owner, occupant, lien claimant or otherwise,
in the several tracts of real estate described in the petition and notice.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-43) (from Ch. 24, par. 9-3-43)
Sec. 9-3-43.
The cause shall be heard as suits to foreclose mortgages on
real estate. The court shall ascertain and determine the amount of the
liens created under this Division 3 due as of the date of the entry of its
orders from each of the several tracts of real estate, specifying
separately the amount due on account of each tract. Judgment shall be
entered against the respective tracts for the amount of such assessment of
installments thereof, including interest, penalties and cost of suit. The
cost shall be apportioned to the respective tracts as the court determines
proper. In such judgment the court shall also order the respective tracts
of real estate sold by the general county officer having authority to
receive state and county taxes, unless the amount of the judgment
determined against the same shall be paid by a short date to be fixed by
the court. Appeals may be prosecuted as in other civil cases.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-44) (from Ch. 24, par. 9-3-44)
Sec. 9-3-44.
Upon expiration of the time for payment as fixed by the order
of the court, the general county officer having authority to receive state
and county taxes shall advertise the sale of the several tracts of real
estate on which the amount adjudged against the same by the order has not
been paid. The advertisement shall be made in some newspaper published and
of general circulation in the county at least 10 days prior to the date of
sale. At such sale each lot, tract or parcel of land shall be sold
separately, free and clear of all liens and encumbrances, except for
general taxes and unpaid special assessments not included in the judgment,
the lien for which shall remain unimpaired, to the highest bidder for cash.
The sale shall not be complete until the purchase price is paid. No tract
shall be sold for less than the costs of sale, costs adjudged by the court,
and amount of all past due installments of special assessments created by
this Division 3 as determined by the court. The person so selling shall
make, execute and deliver to the purchaser a certificate of sale which
shall describe the real estate sold, recite the date of sale, the name and
address of the purchaser, the amount bid and that the purchaser is entitled
to a deed conveying fee simple title to the premises upon expiration of the
period of redemption and upon compliance by the purchaser or his assignee
with the provisions of this Division 3. The proceeds received from such
sale shall be disbursed in the following order: first, all costs and
expenses of sale and suit shall be fully paid; second, the amount necessary
to satisfy the special assessments shall be transferred to the proper
officer; third, the residue, if any, shall be delivered to the court to be
turned over to the owner, mortgagee or such other person as shall establish
right thereto. A report of sales shall be made promptly to the court
together with a copy of each certificate of sale issued.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-45) (from Ch. 24, par. 9-3-45)
Sec. 9-3-45.
Any owner or person interested in any real estate sold under
the provisions of this Division 3 has the right to redeem from such sale at
any time within 2 years from date of sale upon payment of the amount bid
and paid by the purchaser as set out in the certificate of sale, plus all
taxes and assessments thereafter paid by the purchaser, together with
interest on all such sums at the rate of the greater of 9% per annum or
70% of the prime commercial rate in effect on the date the special assessment
ordinance is adopted. Interest shall run from date of sale
(and from date of payment of taxes and assessments in case of such
payments) to date of payment to the clerk of the court. An entry of all
such redemptions shall be made on the court docket. The clerk shall
immediately notify the purchasers of such redemption and that he may obtain
his money upon surrender of certificate of purchase.
(Source: P.A. 82-686.)
(65 ILCS 5/9-3-46) (from Ch. 24, par. 9-3-46)
Sec. 9-3-46.
Subsequent to the issuance of the certificate of sale and 30
days prior to the expiration of the period of redemption the purchaser or
his assignee shall cause written notice of the date of the expiration of
the period of redemption to be served on the occupant of the premises
described in the certificate, if the premises are occupied and proof of
such notice shall be made to the court. The purchaser or his assignee shall
also cause notice to be published in at least one issue of some newspaper
published and of general circulation in the municipality where the real
estate is situated, if there is such newspaper. Otherwise such publication
shall be made in some newspaper published and of general circulation in the
county, addressed to "All Owners, Parties Concerned and Persons
Interested", setting forth a description of the real estate sold and not
then redeemed, the date of sale, the date of the expiration of the period
of redemption, when and where application will be made for deed to be
issued pursuant to the provisions of this Division 3, and the docket number
of the foreclosure proceedings. Such notice shall be published subsequent
to the issuance of the certificate of sale and at least 30 days prior to
the date of the expiration of the period of redemption.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-47) (from Ch. 24, par. 9-3-47)
Sec. 9-3-47.
The purchaser or his assignee shall pay all taxes and
assessments on real estate sold under the provisions of this Division 3.
Notation of such payments shall be made on the docket of the court, and the
same shall be repaid if the real estate is redeemed, together with interest
at the rate of the greater of 9% per annum or 70% of the prime commercial
rate in effect on the date the special assessment ordinance is adopted.
(Source: P.A. 82-686.)
(65 ILCS 5/9-3-48) (from Ch. 24, par. 9-3-48)
Sec. 9-3-48.
A deed conveying the fee simple title to the premises, free
and clear of all liens and encumbrances, except unpaid general taxes and
special assessments, or installments thereof, shall be issued to the
purchaser at any time after the expiration of the period of redemption upon
proof of payment of all taxes and assessments becoming due subsequent to
date of sale, proof of notice to occupant of date of expiration of period
of redemption, proof of publication of notice to all parties concerned of
the date of expiration of the period of redemption and when and where
application will be made for deed. If the court determines that the
provisions of this Division 3 are complied with, the court shall direct the
general county officer authorized to collect state and county taxes to
execute and deliver to the applicant a deed conveying fee simple title to
the several tracts of real estate, free and clear of all incumbrances, and
liens, except the lien for unpaid general taxes and special assessments, or
installments thereof, the lien as to which shall continue unimpaired. Such
deed shall refer to the judgment of the court and this Division 3 as the
authority by which it is issued. Such deeds shall be recorded as other
deeds conveying real estate. After 30 days from the date of filing the deed
issued under the provisions of this Division 3 in the recorder's office for
recordation, no action shall be instituted to defeat or impair such
conveyance.
(Source: P.A. 84-452; 84-545.)
(65 ILCS 5/9-3-49) (from Ch. 24, par. 9-3-49)
Sec. 9-3-49.
Any municipality levying assessments as provided in this
Division 3 may provide by ordinance for the levy, in addition to the taxes
now authorized by law, and in addition to the amount authorized to be
levied for general corporate purposes, a tax not exceeding .05% of all
taxable property in such municipality to be known as a public benefit tax
for the purpose of paying public benefits levied in accordance with the
provisions of this Division 3. The fund arising therefrom shall be known as
a public benefit fund, which fund shall be kept separate and apart from all
other funds and shall be used solely for the purpose of paying that portion
of the several amounts assessed against any such municipality for public
benefit. However, such municipality shall not extend a tax for the payment
of such public benefit in excess of the amount required annually to pay the
principal and interest of the installments of such public benefit as it
matures.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/9-3-50) (from Ch. 24, par. 9-3-50)
Sec. 9-3-50.
The funds of each assessment created under this Division 3
shall be kept by the treasurer of such municipality in a separate bank
account.
(Source: Laws 1961, p. 576.)
(65 ILCS 5/Art. 9 Div. 4 heading)
(65 ILCS 5/9-4-1) (from Ch. 24, par. 9-4-1)
Sec. 9-4-1.
Property not within the corporate limits but contiguous to any
local improvement made by a municipality pursuant to the provisions of this
Article may be charged by the corporate authorities of the municipality in
an amount not greater than the benefit conferred by the local improvement
on such property. This Division 4 shall apply only to municipalities of
less than 500,000 inhabitants and shall not be exercised with respect to
any contiguous property where such property is included within the
corporate limits of another municipality.
(Source: Laws 1965, p. 668.)
(65 ILCS 5/9-4-2) (from Ch. 24, par. 9-4-2)
Sec. 9-4-2.
The corporate authorities of a municipality who intend to
charge benefits conferred by local improvements on property not within the
corporate limits of such municipality against such property, as provided in
this Division 4, shall commence a proceeding by filing a petition in the
circuit court of the county in which the municipality making such local
improvement is situated, or if such municipality is situated in more than
one county and such proposed improvement lies in more than one county, then
in the circuit court of the county in which the major part of the territory
to be affected thereby is situated. Such petition shall contain (i) a
statement that the board of local improvements or the committee on local
improvements of such municipality is considering the making of a local
improvement to be paid for by special assessment or by special tax and that
the local improvement will benefit property not within the corporate limits
of such municipality but contiguous to such local improvement; (ii)
description of the extent, nature, kind, character and (when an estimate of
the cost thereof is required under the provisions of Division 2 of this
Article) the estimated cost of the proposed local improvement; (iii) a
description of the lots, blocks, tracts, or parcels of property not within
such municipality which the corporate authorities determine may be charged
under this Division 4 with any part of the cost for making such local
improvement, together with the name and address of the person or persons to
whom the tax bill was sent for general taxes on each such lot, block, tract
or parcel for the last preceding year; and (iv) a statement of the time and
place of the public hearing, if any, to be held on such local improvement
by the board of local improvements or the committee on local improvements.
Upon the filing of such petition, the clerk of the circuit court shall
issue a summons as in civil cases to the person or persons to whom such tax
bills were sent as set forth in such petition. The board of local
improvements or the committee on local improvements shall give to each
person to whom such summons is issued notice of the time and place of the
public hearing on such local improvement in the same manner as such notice
is given to persons with respect to property within such municipality, all
in accordance with the applicable provisions of Division 2 or Division 3 of
this Article. Any person to whom such summons is issued shall have the
right to appear and be heard at such public hearing in accordance with the
provisions of Division 2 or Division 3 of this Article, and the circuit
court shall upon application of such municipality, enter an order staying
further proceedings on such petition filed pursuant to this Division 4
pending the filing of and hearing on the petition contemplated by Division
2 or Division 3 of this Article, and shall consolidate for hearing by the
court such petition filed under Division 2 or Division 3 of this Article
with such petition filed under Division 4 of this Article. The procedure
and issues on the hearing on a petition filed under Division 4 of this
Article shall be the same, as near as may be, as the procedure and issues
set forth in Division 2 or Division 3 of this Article, and at such hearing,
the circuit court shall hear and determine all objections as to the amount
set as a benefit to such property.
(Source: P.A. 76-1549.)
(65 ILCS 5/9-4-3) (from Ch. 24, par. 9-4-3)
Sec. 9-4-3.
The amount set by order of the circuit court shall be a lien
against such property enforceable in the same manner as a lien created
under Division 2 or Division 3 of this Article.
(Source: P.A. 76-1549.)
(65 ILCS 5/Art. 9 Div. 5 heading)
(65 ILCS 5/9-5-1) (from Ch. 24, par. 9-5-1)
Sec. 9-5-1.
Whenever a municipal ordinance or an annexation agreement
authorized under Section 11-15.1-1 of this Code
requires the installation of water mains, sanitary sewers, drains, or other
facilities for sewers and drains, the construction of any roadways, or
the installation of any traffic signals or other traffic related
improvements as a condition of either the acceptance
of a preliminary or final subdivision or
plat described in Section 11-12-12 or a preliminary or final planned
unit development plan or the issuance of a building permit and where,
in the opinion of the corporate authorities, the facilities,
roadways, or improvements may be used for the benefit of property not
in the subdivision or planned unit development or outside the property
for which a building permit has been issued, and the water
mains, sanitary sewers, drains, or other facilities,
roadways, or improvements are to be dedicated to the public, the
corporate authorities may by contract with the subdivider or permittee
agree to reimburse and may reimburse the subdivider or permittee for a
portion of the cost of the facilities, roadways, and
improvements from fees charged to owners of property not within the
subdivision, planned unit development, or property for which a
building permit has been issued when and as collected from the owners.
The contract shall describe the property
outside the subdivision, planned unit development, or property
for which a building permit has been issued that may reasonably
be expected to benefit from the facilities, roadways, or improvements
that are required to be constructed under the contract and
shall specify the amount or proportion of the cost of the
facilities, roadways, or improvements that is to be
incurred primarily for the benefit of that property. The
contract shall provide that the municipality shall collect fees
charged to owners of property not within the subdivision,
planned unit development, or property for which a building permit has been
issued at any time before the connection to and use of the facilities,
roadways, or improvements by the respective
properties of each owner. The contract
may contain other and further provisions and agreements concerning the
construction, installation, completion, and acceptance of the facilities,
roadways, or improvements that the corporate authorities in their sole opinion
deem proper and may also provide for the payment to the subdivider or
permittee of a reasonable amount of interest on the amount expended by the
subdivider or permittee in completing the facilities, roadways, and
improvements, the interest to be calculated from and after the date of
completion and acceptance of the facilities, roadways, and improvements.
(Source: P.A. 87-539.)
(65 ILCS 5/9-5-2) (from Ch. 24, par. 9-5-2)
Sec. 9-5-2.
Any contract entered into between the corporate authorities of a
municipality and a subdivider pursuant to Section 9-5-1 shall be filed with
the recorder of each county in which all or a
part of the property
affected thereby is located. The recording of the contract in this manner
shall serve to notify persons interested in such property of the fact that
there will be a charge in relation to such property for the connection to
and use of the facilities constructed under the contract.
(Source: P.A. 83-358.)
(65 ILCS 5/9-5-3) (from Ch. 24, par. 9-5-3)
Sec. 9-5-3.
This Division 5 does not apply to any municipality which is a home rule
unit. This Division 5 is not a prohibition upon the contractual and
associational powers granted by Article VII, Section 10 of the Illinois
Constitution.
(Source: P.A. 77-2463.)
Structure Illinois Compiled Statutes
65 ILCS 5/ - Illinois Municipal Code.
Article 1 - General Provisions
Article 2 - Organization Of Municipalities
Article 4 - Commission Form Government
Article 5 - Managerial Form Of Municipal Government
Article 6 - Strong Mayor Form Government
Article 9 - Local Improvements