Subdivision 1. Repair cost statement. For a joint county drainage system the auditor of a county that has made repairs may present a repair cost statement at the end of each year, or other convenient period after completion, to each affected county. The repair cost statement must show the nature and cost of the repairs to the drainage system and must be based on the original apportionment of cost following the establishment of the drainage system. If a board approves the repair costs, the amount of the statement must be paid to the county submitting the statement.
Subd. 2. Repair cost statement not paid. (a) If a county does not pay the amount of the repair cost statement, the board of an affected county may petition the joint county drainage authority. The petition must:
(1) show the nature and necessity of the repairs made to the drainage system in the county during the period;
(2) show the cost of the repairs; and
(3) request the drainage authority to apportion the costs, by order, among the affected counties.
(b) When the petition is filed, the drainage authority shall, by order, set a time and location for a hearing to apportion the costs, and direct the auditor to give notice of the hearing to each affected county by publication and notice by mail to its auditor. At or before the hearing, the auditor of each affected county, except the petitioner, shall file with the drainage authority a statement showing:
(1) all repairs made to the drainage system in that county, not previously reimbursed;
(2) the nature and necessity of the repairs; and
(3) the cost of the repairs.
(c) The drainage authority has jurisdiction over the affected counties and shall hear all interested parties. The drainage authority shall determine which repairs were necessary and reasonable and proper costs. For the allowed repairs the drainage authority shall balance the accounts among the affected counties, by charging each county with its proportionate share of the cost of all repairs made and crediting each county with the amount paid for the repairs. The drainage authority shall order a just reimbursement among the affected counties. A certified copy of the order must be filed by the auditor with the auditors of affected counties, and the boards shall make the required reimbursement.
1990 c 391 art 5 s 92
Structure Minnesota Statutes
Section 103E.005 — Definitions.
Section 103E.011 — Drainage Authority Powers.
Section 103E.015 — Considerations Before Drainage Work Is Done.
Section 103E.021 — Planting Ditches With Perennial Vegetation.
Section 103E.031 — Connection With Drains In Adjoining States.
Section 103E.035 — Defective Notice.
Section 103E.041 — Personal Service In Lieu Of Other Methods Of Notice.
Section 103E.043 — Informal Meetings.
Section 103E.045 — Failure To Attend Hearings; Drainage Authority.
Section 103E.051 — Defective Proceedings.
Section 103E.055 — Reimbursing Cost Of Former Surveys When Used Later.
Section 103E.061 — Right Of Entry.
Section 103E.065 — Drainage Inspectors.
Section 103E.067 — Ditch Buffer Strip; Annual Reporting.
Section 103E.071 — County Attorney.
Section 103E.075 — Obstructing Drainage System.
Section 103E.081 — Crimes Related To Drainage Systems; Penalties.
Section 103E.085 — Enforcement.
Section 103E.095 — Appeal From Orders Dismissing Or Establishing Drainage Systems.
Section 103E.097 — Attorney Fees On Appeal.
Section 103E.101 — Drainage Proceeding And Construction Records.
Section 103E.105 — Advice About Drainage Questions.
Section 103E.111 — Field Surveys And Investigations By Director.
Section 103E.115 — Hydrological And Drainage Information.
Section 103E.121 — Drain Tile; Manufacturing Studies.
Section 103E.212 — New Drainage System Projects.
Section 103E.215 — Improving Drainage Systems.
Section 103E.221 — Improving Outlets.
Section 103E.227 — Impounding, Rerouting, And Diverting Drainage System Waters.
Section 103E.231 — Dismissing Or Delaying Proceedings; Petitioners.
Section 103E.235 — Drainage System In Two Or More Counties.
Section 103E.238 — County Attorney Review Of Petition And Bond.
Section 103E.245 — Preliminary Survey And Preliminary Survey Report.
Section 103E.251 — Filing Preliminary Survey Report.
Section 103E.255 — Commissioner's Preliminary Advisory Report.
Section 103E.261 — Preliminary Hearing.
Section 103E.265 — Order For Detailed Survey And Survey Report.
Section 103E.271 — Detailed Survey.
Section 103E.275 — Engineer's Variance From Drainage Authority Order.
Section 103E.281 — Soil Survey.
Section 103E.285 — Detailed Survey Report.
Section 103E.291 — Filing Detailed Survey Report.
Section 103E.295 — Revising Engineer's Detailed Survey Report After Acceptance.
Section 103E.301 — Commissioner's Final Advisory Report.
Section 103E.305 — Viewers' Appointment And Qualification.
Section 103E.311 — Viewer Duties.
Section 103E.315 — Assessing Drainage Benefits And Damages.
Section 103E.321 — Viewers' Report.
Section 103E.323 — Property Owners' Report.
Section 103E.325 — Final Hearing Notice.
Section 103E.331 — Jurisdiction Of Property By Drainage Authority.
Section 103E.335 — Proceedings At Final Hearing.
Section 103E.341 — Drainage Authority Final Order.
Section 103E.345 — Apportioning Cost For Joint County Drainage Systems.
Section 103E.351 — Redetermining Benefits And Damages.
Section 103E.401 — Use Of Drainage System As Outlet.
Section 103E.405 — Outlets In Adjoining States.
Section 103E.411 — Drainage System As Outlet For Municipality.
Section 103E.501 — Contract And Bond.
Section 103E.505 — Awarding Construction Contract.
Section 103E.511 — Contract Not Awarded; Excessive Bids Or Costs.
Section 103E.515 — Damages; Payment.
Section 103E.521 — Construction Supervision.
Section 103E.525 — Constructing And Maintaining Bridges And Culverts.
Section 103E.526 — Constructing Road Instead Of Bridge Or Culvert.
Section 103E.53 — Rules To Standardize Forms.
Section 103E.531 — Inspecting Drainage Construction; Partial Payments.
Section 103E.535 — Partial Payment Of Retained Contract Amounts.
Section 103E.541 — Extending Time On Contracts.
Section 103E.545 — Reducing Contractor's Bond.
Section 103E.551 — Contractor Default.
Section 103E.555 — Accepting Contract.
Section 103E.601 — Drainage Lien Statement.
Section 103E.605 — Effect Of Filed Drainage Lien.
Section 103E.611 — Paying Drainage Liens And Interest.
Section 103E.615 — Enforcing Assessments.
Section 103E.621 — Satisfying Liens.
Section 103E.625 — Subdivision By Platting; Liens Apportioned.
Section 103E.631 — Apportioning Liens.
Section 103E.635 — Drainage Bond Issues.
Section 103E.641 — Drainage Funding Bonds.
Section 103E.645 — Allowance And Payment Of Fees And Expenses.
Section 103E.651 — Drainage System Account.
Section 103E.655 — Paying Drainage System Costs.
Section 103E.661 — Examining And Establishing Drainage System Accounts; State Auditor.
Section 103E.705 — Repair Procedure.
Section 103E.711 — Cost Apportionment For Joint County Drainage Systems.
Section 103E.715 — Repair By Petition.
Section 103E.721 — Replacement And Hydraulic Capacity Of Bridges And Culverts.
Section 103E.725 — Cost Of Repair.
Section 103E.728 — Apportioning Repair Costs.
Section 103E.729 — Apportioning Repair Costs; Alternative Option.
Section 103E.731 — Assessment; Bonds.
Section 103E.735 — Drainage Systems; Repair Fund.
Section 103E.741 — Property Not Assessed Benefits; Hearing.
Section 103E.745 — Cost Of Repair Exceeding Benefits In Anoka County.
Section 103E.801 — Consolidating Or Dividing Drainage Systems.
Section 103E.805 — Removing Property From Drainage System.
Section 103E.806 — Partial Abandonment Of Drainage System.
Section 103E.811 — Abandoning Drainage System.
Section 103E.812 — Transfer Of All Or Part Of Drainage System.