(1) As used in this section, the term:
(a) “Construction management entity” means a licensed general contractor or a licensed building contractor, as defined in s. 489.105, who coordinates and supervises a construction project from the conceptual development stage through final construction, including the scheduling, selection, contracting with, and directing of specialty trade contractors, and the value engineering of a project.
(b) “Construction project” means any planned or unforeseen fixed capital outlay activity authorized under s. 255.31. A construction project may include:
1. A grouping of minor construction, rehabilitation, or renovation activities.
2. A grouping of substantially similar construction, rehabilitation, or renovation activities.
(c) “Continuing contract” means a contract with a construction management entity for work during a defined time period on construction projects described by type, which may or may not be identified at the time of entering into the contract.
(d) “Department” means the Department of Management Services.
(2) To assist in the management of state construction projects, the department may select and contract with construction management entities that:
(a) Are competitively selected by the department pursuant to s. 287.055; and
(b) Agree to follow the advertising and competitive bidding procedures that the department is required to follow if the department is managing the construction project directly.
(3) The department’s authority under subsection (2) includes entering into a continuing contract for construction projects in which the estimated construction cost of each individual project under the contract does not exceed $2 million.
(4) The department may require the construction management entity, after having been selected for a construction project and after competitive negotiations, to offer a guaranteed maximum price and a guaranteed completion date. If so required, the construction management entity must secure an appropriate surety bond pursuant to s. 255.05 and must hold construction subcontracts. If a project solicited by the department pursuant to s. 287.055 includes a grouping of construction, rehabilitation, or renovation activities or substantially similar construction, rehabilitation, or renovation activities costing up to $1 million, the department may require the construction management entity to provide a separate guaranteed maximum price and a separate guaranteed completion date for each grouping included in the project.
(5) The department shall adopt rules for state agencies using the services of construction management entities under contract with the department.
History.—s. 1, ch. 2009-227.
Structure Florida Statutes
Title XVIII - Public Lands and Property
Chapter 255 - Public Property and Publicly Owned Buildings
255.01 - Proceeds of Insurance May Be Used to Replace Property Destroyed.
255.02 - Boards Authorized to Replace Buildings Destroyed by Fire.
255.03 - Proceeds of Insurance to Be Paid Into State Treasury; Disbursement of Funds.
255.04 - Preference to Home Industries in Building Public Buildings.
255.041 - Separate Specifications for Building Contracts.
255.042 - Shelter in Public Buildings.
255.043 - Art in State Buildings.
255.045 - Cleanup After Events Held on Public Property.
255.05 - Bond of Contractor Constructing Public Buildings; Form; Action by Claimants.
255.051 - Public Bids; Check or Draft as Good Faith Deposit.
255.0515 - Bids for State Contracts; Substitution of Subcontractors.
255.0516 - Bid Protests by Educational Boards.
255.0517 - Owner-Controlled Insurance Programs for Public Construction Projects.
255.0518 - Public Bids; Bid Opening.
255.052 - Substitution of Securities for Amounts Retained on Public Contracts.
255.0525 - Advertising for Competitive Bids or Proposals.
255.065 - Public-Private Partnerships.
255.073 - Timely Payment for Purchases of Construction Services.
255.074 - Procedures for Calculation of Payment Due Dates.
255.076 - Award of Court Costs and Attorney’s Fees.
255.077 - Project Closeout and Payment of Retainage.
255.078 - Public Construction Retainage.
255.099 - Preference to State Residents.
255.0991 - Contracts for Construction Services; Prohibited Local Government Preferences.
255.0992 - Public Works Projects; Prohibited Governmental Actions.
255.101 - Contracts for Public Construction Works; Utilization of Minority Business Enterprises.
255.102 - Contractor Utilization of Minority Business Enterprises.
255.103 - Construction Management or Program Management Entities.
255.21 - Special Facilities for Physically Disabled.
255.211 - Special Symbol May Be Displayed.
255.22 - Reconveyance of Lands Not Used for Purpose Specified.
255.249 - Department of Management Services; Responsibility; Department Rules.
255.25 - Approval Required Before Construction or Lease of Buildings.
255.2501 - Lease of Space Financed With Local Government Obligations.
255.2502 - Contracts Which Require Annual Appropriation; Contingency Statement.
255.2503 - Contracts for Lease of Buildings; Prohibited Provisions.
255.251 - Energy Conservation and Sustainable Buildings Act; Short Title.
255.252 - Findings and Intent.
255.253 - Definitions; Ss. 255.251-255.2575.
255.254 - No Facility Constructed or Leased Without Life-Cycle Costs.
255.256 - Energy Performance Index.
255.257 - Energy Management; Buildings Occupied by State Agencies.
255.2575 - Energy-Efficient and Sustainable Buildings.
255.259 - Florida-Friendly Landscaping on Public Property.
255.28 - Department Authority to Acquire Land With or for Facility Thereon.
255.29 - Construction Contracts; Department Rules.
255.32 - State Construction Management Contracting.
255.45 - Correction of Firesafety Violations in Certain State-Owned Property.
255.451 - Electronic Firesafety and Security System.
255.501 - Building and Facilities Act; Short Title.
255.502 - Definitions; Ss. 255.501-255.525.
255.503 - Powers of the Department of Management Services.
255.505 - Creation of the Pool.
255.507 - Determination of Qualified Facilities.
255.508 - Participation in Pool.
255.509 - Request for Advisory Statement.
255.51 - Determination of Rental Rates.
255.511 - Factors to Be Considered in Establishing Rental Rates.
255.513 - Powers of the Division of Bond Finance and the Department of Management Services.
255.514 - Division of Bond Finance; Revenue Bonds.
255.515 - Issuance of Obligations by the Division.
255.516 - Security for Payment of Obligations.
255.517 - Anticipation Obligations.
255.518 - Obligations; Purpose, Terms, Approval, Limitations.
255.519 - Variable Rate Obligations.
255.52 - Approval by State Board of Administration.
255.522 - State and Political Subdivisions Not Liable on Obligations.
255.523 - Exemption From Taxes.
255.524 - Obligations Issued Constitute Legal Investments.
255.525 - Inconsistent Provisions of Other Laws Superseded.
255.5576 - Consideration of Energy-Efficient Materials; High-Energy Lighting.
255.60 - Special Contracts With Charitable or Not-for-Profit Organizations.