31-2-13.1. Rules--Promulgation.
The Transportation Commission of the Department of Transportation may adopt rules pursuant to chapter 1-26, governing the following conditions in highway construction contracts:
(1)Site conditions;
(2)Suspensions of work ordered by the state (other than a suspension of work caused by the fault of the contractor or by weather);
(3)Material changes in the scope of work specified in the contract.
Source: SL 1989, ch 249.
Structure South Dakota Codified Laws
Title 31 - Highways and Bridges
Chapter 02 - Administration Of State Highways
Section 31-2-13.1 - Rules--Promulgation.
Section 31-2-13.2 - State highway fund--Use and expenditure of moneys--Purpose.
Section 31-2-14.1 - Rules to define "administrative purposes".
Section 31-2-14.2 - Use of state highway fund.
Section 31-2-14.3 - Annual appropriation to Department of Revenue--Distribution.
Section 31-2-18 - Employment of persons with developmental disabilities.
Section 31-2-19 - Construction and improvement of roads--Location of material--Public meetings.
Section 31-2-20 - Adoption of standard plans and specifications.
Section 31-2-22 - Advice at county's request on maintaining its highway system.
Section 31-2-23 - Dissemination of highway information--Tourism publications.
Section 31-2-24 - Contracts for tourist publicity.
Section 31-2-27 - Disposition of property no longer useful.
Section 31-2-32 - Auction sale of passenger automobiles.
Section 31-2-33 - Cooperation in research projects for road development.
Section 31-2-34 - Action against state on construction contract--Venue of trial.
Section 31-2-35 - Hearing and determination of action against state--Right of appeal.
Section 31-2-36 - Service of process on state.
Section 31-2-37 - Time for actions against state.
Section 31-2-38 - Award of damages and costs--Payment by state.
Section 31-2-39 - Final judgment against state--Payment from state highway fund.