Texas Statutes
Subchapter E. Judicial Proceedings
Section 315.095. Suspension of Work

Sec. 315.095. SUSPENSION OF WORK. When suit is brought under Section 315.092, the municipality or the contractor may suspend performance of work until a final judgment is rendered in the case and all appellate remedies are exhausted.
Acts 1995, 74th Leg., ch. 165, Sec. 1, eff. Sept. 1, 1995.